This report examines whether NSW Health effectively planned and delivered major capital works to meet the demand for health services in New South Wales.

The report found that NSW Health has substantially expanded health infrastructure across New South Wales since 2015. However, the program was driven by Local Health District priorities without assessment of the State’s broader and future‑focussed health requirements.

The report found that unclear decision making roles and responsibilities between Health Infrastructure and the Ministry of Health limited the ability of NSW Health to effectively test and analyse investment options.

Project delays and budget overruns on some major projects indicate that Health Infrastructure's project governance, risk assessment and management systems could be improved.

The Auditor‑General recommends that NSW Health ensure its capital projects offer the greatest value to New South Wales by establishing effective policy guidance and enhancing project governance and management systems.

Read full report (PDF)

Since 2011–12, NSW Health has aimed to improve its facilities and build 'future focused' infrastructure. The NSW Government’s 2015–16 election commitments established a four-year $5.0 billion capital program for NSW Health to build and upgrade more than 60 hospitals and health services. The 2019–20 State Budget committed a further $10.1 billion over four years for another 29 projects. This is the largest investment to date on health capital works in New South Wales.

Recent reviews of infrastructure have recognised that population and demographic growth will require a change in the delivery and composition of health infrastructure, including considering greater use of non-traditional, non-capital health service options and assets.

To ensure that expenditure on capital works represents the best value for money, NSW Health's business cases need to be robust and supported by evidence that demonstrates they are worthy investments. The NSW Process of Facility Planning has been the main framework guiding the detailed planning and development of NSW Health's capital works proposals. This framework was developed by the then NSW Department of Health in 2010. Its aim is to ensure investment proposals are supported by rigorous planning processes that address health service needs and provide value for money.

Infrastructure projects of the complexity and scale being delivered by NSW Health carry inherent risks. For example, unplanned cost escalations can potentially impact on the State’s finances. Unforeseen delays can also reduce the intended benefits. The growth in the State’s health capital spend and project profile, means its exposure to such risks has increased over time.

The objective of this audit was to assess the effectiveness of planning and delivery of major capital works to meet demand for health services in New South Wales. To address this objective, the audit examined whether:

• the Ministry of Health has effective procedures for planning and prioritising investments in major health capital works
• Health Infrastructure develops robust business cases for initiated major capital works that reliably inform government decision making
• Health Infrastructure has effective project governance and management systems that support delivering projects on-time, within budget and achievement of intended benefits.

The audit focused on the Ministry of Health and Health Infrastructure – being the lead agencies within NSW Health responsible for prioritising, planning and delivering major health capital works across the State. The audit examined 13 business cases for eight discrete projects over a ten-year period.

Over the period of review, NSW Government policies for business case development and submission have emphasised that effective governance arrangements are critical to a proposal's successful implementation.

NSW Health's Process of Facility Planning similarly highlights the importance of effective governance and project management for achieving good outcomes. It prescribes a general governance structure managed by Health Infrastructure that can be tailored to the planning and delivery of health infrastructure projects greater than $10.0 million.

The three major hospital redevelopments examined in metropolitan, regional and rural areas had a combined Estimated Total Cost of more than $1.2 billion and comprised eight discrete projects and 13 separate business cases.

Almost all these projects experienced delivery challenges which impacted achievement of their original objectives and intended benefits. This is expected in complex and large-scale health infrastructure programs. However, in some projects the impacts were significant and resulted in substantial delays, unforeseen costs, and diversion of resources from other priority areas.

Our review of the selected case studies highlighted opportunities for enhancing governance and project management. Specifically, it indicates a need for improving transparency in the management of contingencies, risk management and assessments particularly relating to adverse site conditions and the selection of contractors. There is also a need to strengthen forward planning for options to address unfunded priorities within business cases that risk complicating the delivery of future project stages resulting in unforeseen costs and potentially avoidable budget overruns.

In February 2017, the Ministry's Capital Strategy Group approved the use of surplus funds of $13.76 million from Stage 1 of the Hornsby Ku-ring-gai Hospital Redevelopment for new works deemed needed to support Stage 2. Following this decision, Health Infrastructure finalised and submitted a business case addendum for Stage 1 to the Ministry in March 2017, addressing the new works comprising a two-storey building for medical imaging and paediatric floors. The business case addendum also addressed options to fit out and procure major medical imaging equipment. The Ministry approved the Stage 1 business case in July 2017, noting the Ministry's Capital Strategy Group had already approved the use of remaining Stage 1 funds to deliver the new works.

Stage 1 was completed in 2015, almost two years before the Stage 1 business case addendum was prepared in February 2017.

The Ministry's decision to approve the new works using $13.76 million of surplus Stage 1 funds did not comply with the NSW Treasury Circular TC 12/20. This policy establishes the Treasurer's approval must be sought and received before a new capital project with an Estimated Total Cost of $5.0 million or more can be approved by NSW Health. The Ministry therefore exceeded its delegated authority in making this decision, as it was not evident it had sought and received the Treasurer's approval prior to doing so.

Consequently, the surplus Stage 1 funds should not have been used by the Ministry to deliver new works in the circumstances. Instead, they should have been released from the Stage 1 project in accordance with established NSW Health procedures, and the Stage 1 Estimated Total Cost revised down accordingly. This did not occur, and NSW Health ultimately directed $11.0 million in surplus Stage 1 funds to the new works.

These circumstances indicate a need to strengthen transparency and accountability within NSW Health for the approval of new projects, and how contingency funds are used in the management of major health capital works. They also demonstrate the impact of weaknesses with options appraisal as the initial Stage 1 business case did not consider alternative options for addressing the initially unfunded works later covered by the Stage 1 business case addendum and ultimately funded from the Stage 1 contingency provision.

In addition to proposing the above-noted new works, the 2017 Stage 1 Business Case Addendum for the Hornsby-Ku-ring-gai development sought to retrospectively address the estimated funding gap of around $14.0 million for the internal fit out, supply of major medical imaging equipment, and cost to operate the medical imaging service at Hornsby Ku-ring-gai Hospital also not addressed in the originally Stage 1 business case.

The Stage 1 business case addendum considered various procurement options to purchase and run the medical imaging services ranging from State operation purchase options to private operation purchase options.

It recommended outsourcing the operation and provision of equipment to the private sector based on estimated savings to the public sector initially of around $650,000 per annum reducing over time to $270,000. The Ministry endorsed this option in June 2017, but it did not ultimately proceed.

A July 2018 report to the Executive Steering Committee on the project shows NSW Health later decided to deliver operation of the medical imaging unit 'traditionally' with an updated estimate of the cost at approximately $16.4 million. The report also shows the Ministry supported the costs now being met by the Northern Sydney Local Health District.

This means the funding gap previously identified in the Stage 1 business case addendum for fitting out the medical imaging building and supply of major medical equipment would need to be met fully by the State, representing a $16.4 million cost overrun for the project.

Examined reports to the Executive Steering Committee show this was largely funded by the Northern Sydney Local Health District via the disposal of land realising approximately $15.0 million in proceeds.

This initially unforeseen cost, along with the additional $11.0 million for the new works approved under the Stage 1 business case addendum, were ultimately merged with the Stage 2 project initially approved in 2017–18 with an Estimated Total Cost of $200 million.

The 2019–20 State Budget provided an additional $65.0 million for a further Stage 2A to deliver additional built capacity to support outpatient services, enhanced allied health services, re-housed community health services and the delivery of prioritised clinical services unfunded as part of Stage 2. The funds were approved based on an Investment Decision Template (IDT) that examined two options in addition to the base case representing scoping alternatives to the preferred master planned capital solution.

However, we found the IDT showed around 23 per cent of the $65.0 million sought (i.e. $15.0 million) was to be allocated to fund the deficit in Stage 2, which had arisen as a result of project delays due to adverse site conditions. This was not discussed in the IDT.

The February 2020 report to the Executive Steering Committee shows a combined Stage 2 and 2A final forecast cost of $292.6 million against a potential budget of $290.7 million representing an overall deficit for the project of around 0.6 per cent.

However, this favourable final budget position does not transparently show the funding challenges experienced over the project's implementation to-date. The three major budget issues include:

• inappropriate use of around $11.0 million in Stage 1 contingency for originally unfunded works contrary to Treasury policy
• the additional $16.4 million cost unforeseen in the Stage 1 business case for delivering medical imaging services mostly funded through the sale of land
• an additional $15.0 million from Stage 2A to cover the budget overrun in Stage 2 due to adverse site conditions.

The cumulative impact of these events is that Stages 1 and 2 of the Hornsby project cost approximately $42.4 million than it should have in the circumstances around 14 per cent more than what the revised combined Estimated Total Cost for both stages should have been after releasing the $11.0 million in surplus Stage 1 funds, with Stage 2 delayed by around 14 months.

Major construction projects often experience adverse site conditions which can be difficult to fully detect in advance. However, we found this was a common occurrence in the projects we examined sometimes with significant time and/or budget impacts indicating scope to enhance related risk and cost assessments. Specifically:

• Hornsby Ku-ring-gai Hospital Redevelopment Stage 2: adverse site conditions during demolition works resulted in an 11-month delay for delivering the medical imaging unit and 14-month delay completing Stage 2 main works including need for additional $15.0 million in funds to cover the resultant budget deficit for the project.
• Blacktown Mt Druitt Hospital Redevelopment Stage 2: adverse site conditions combined with project complexity delayed completion of the early works by approximately five months. This contributed to the delay in completing the main construction works which occurred around nine months later than planned in the business case.
• Dubbo Health Service Redevelopment Stages 3 and 4: Health Infrastructure advised adverse site conditions including asbestos containing materials and ground conditions delayed works for the main building with completion forecast for March 2021, around 21 months later than planned in the final business case. This resulted in the need for additional $13.5 million to cover increased construction costs and risks, increasing the Stage 3 and 4 forecast final cost from $150 million to $163.5 million as at February 2020.

These examples indicate a risk the cumulative impact of adverse site conditions may be substantial when measured across both time and Health Infrastructure's full delivery program. They also point to potential for Health Infrastructure to achieve efficiencies and improved outcomes from strengthening its approach to assessing and mitigating the risks from adverse site conditions.

Main construction works on Stage 1 of the Dubbo Health Service Redevelopment were completed in October 2015, approximately 13 months later than planned in the final business case. Delays were mainly due to insolvency of the early works contractor resulting in their departure from the project. The ensuing 11-month delay in completing the early works significantly impacted the overall schedule and delivery of main construction works.

The insolvency event was significant as it affected nine separate Health Infrastructure projects – three of which had yet to reach practical completion. It also affected state-funded projects in other sectors. It resulted in the need for additional funding of $11.5 million that was provided in the 2014–15 State Budget increasing the total Stage 1 and 2 budget from $79.8 million to $91.3 million.

Health Infrastructure’s analysis of lessons learned shows it worked actively to mitigate the impacts of the insolvency event across all affected projects. However, it also indicates a risk the lessons were mainly focused on mitigating the impacts after an insolvency event occurred rather than on prevention.

Although Health Infrastructure initially commissioned a financial assessment of the now insolvent early works contractor before engagement, it did not detect any risks of the impending insolvency and instead concluded the contractor was in a strong financial position. However, the contractor became insolvent shortly after commencement approximately seven months later. This indicates a risk of weaknesses in the assessment performed that was not explicitly addressed by the lessons learned.

Delivery of the main construction works were further impacted by disputes with the main works contractor over the scope of works for the renal unit resulting in Health Infrastructure terminating the contract in November 2016 following lengthy negotiations over several months.

The scope of works relating to the renal unit were ultimately transferred to Stages 3 and 4 and were delivered in December 2019, around five years later than originally planned in the business case.

Health Infrastructure advised the delay was ultimately beneficial to the project because the refurbishment works for the renal unit, initially scheduled for Stages 1 and 2, would have been demolished to accommodate the new Western Cancer Centre proposed after Stages 1 and 2 and currently being delivered in parallel with Stages 3 and 4.

Health Infrastructure advised the actual cost of Stages 1 and 2 was $84.7 million against the budget of $91.3 million. The residual $6.6 million relates to the renal works not delivered during Stage 1 and 2 and transferred to Stage 3 and 4.

Health Infrastructure advised the contractual provisions for mitigating insolvency events 'in-flight' are limited highlighting the importance of proactive and effective due diligence prior to engaging contractors for significant construction projects.

Health Infrastructure's 2017-20 Corporate Plan identifies the development of a quality framework to support delivery of future-focused outcomes as a key organisational priority. Related initiatives within the Corporate Plan describe a framework underpinned by a Quality Committee providing advice on:

• records management, to meet the requirements of the State Records Act 1998
• project assurance, to ensure future focused outcomes and enhance Health Infrastructure's Standards, Policies, Procedures and Guidelines, Templates and Design Guidance Notes
• knowledge management and library services, to promote and leverage from project learnings.

Although Health Infrastructure has some elements of a quality framework it is not yet fully in place. Health Infrastructure advised it had yet to establish the quality framework and related committee described in its Corporate Plan due in part to its focus on responding to the growth of its capital program.

Health Infrastructure's Development and Innovation team has been active in supporting continuous improvement in knowledge and project management including development of business cases. Although useful, these initiatives have relied heavily on leveraging and disseminating insights from Gateway reviews and have not formed part of a systematic quality and continuous improvement framework.

The limited focus on the quality of business cases is reflected in internal performance monitoring and reporting which focuses mainly on tracking the delivery of projects against internal benchmarks, often revised from the baselines in the business case, and expenditure against cashflow targets. There is no evident internal monitoring and/or reporting to the Chief Executive and Board on defined quality metrics linked to business case development and staff capability.

Performance reporting on balanced scorecard metrics has similarly focused mainly on process rather than quality and has been inconsistent in recent years.

Appendix one – Response from agency

Appendix two – About the audit

Appendix three – Performance auditing

Appendix four – Ministry of Health planning tools and guidelines

Appendix five – Streamlined investment decision process for Health Capital Projects

Appendix six – Timeline of business cases and relevant policy guidelines

Copyright notice

© Copyright reserved by the Audit Office of New South Wales. All rights reserved. No part of this publication may be reproduced without prior consent of the Audit Office of New South Wales. The Audit Office does not accept responsibility for loss or damage suffered by any person acting on or refraining from action as a result of any of this material.

Parliamentary reference - Report number #338 - released 12 August 2020

The Auditor-General for New South Wales, Margaret Crawford, released a report today examining whether the Department of Communities and Justice had effective governance and partnership arrangements in place to deliver ‘Their Futures Matter’.

Their Futures Matter was intended to place vulnerable children and families at the heart of services, and direct investment to where funding and programs deliver the greatest social and economic benefits. It was a four-year whole-of-government reform in response to the 2015 Tune Review of out-of-home care.

The Auditor-General found that while important foundations were put in place, and new programs trialled, the key objective to establish an evidence-based whole-of-government early intervention approach for vulnerable children and families in NSW was not achieved.

Governance and cross-agency partnership arrangements to deliver Their Futures Matter were found to be ineffective. 'Their Futures Matter lacked mechanisms to secure cross portfolio buy‑in and did not have authority to drive reprioritisation of government investment', the Auditor-General said.

At the reform’s close, the majority of around $380 million in investment funding remains tied to existing agency programs, with limited evidence of their comparative effectiveness or alignment with Their Futures Matter policy objectives. The reform concluded on 30 June 2020 without a strategy or plan in place to achieve its intent.

The Auditor-General made four recommendations to the Department of Communities and Justice, aimed at improving implementation of outstanding objectives, revising governance arrangements, and utilising the new human services data set to address the intent of the reform. However, these recommendations respond only in part to the findings of the audit.

According to the Auditor-General, ‘Cross-portfolio leadership and action is required to ensure a whole-of-government response to delivering the objectives of Their Futures Matter to improve outcomes for vulnerable children, young people and their families in New South Wales.’

Read full report (PDF)

In 2016, the NSW Government launched 'Their Futures Matter' (TFM) - a whole-of-government reform aimed at delivering improved outcomes for vulnerable children, young people and their families. TFM was the government's key response to the 2015 Independent Review of Out of Home Care in New South Wales (known as 'the Tune Review').

The Tune Review found that, despite previous child protection reforms, the out of home care system was ineffective and unsustainable. It highlighted that the system was not client-centred and was failing to improve the long-term outcomes for vulnerable children and families. The review found that the greatest proportion of relevant expenditure was made in out of home care service delivery rather than in evidence-based early intervention strategies to support children and families when vulnerabilities first become evident to government services (such as missed school days or presentations to health services).

The then Department of Family and Community Services (FACS) designed the TFM reform initiatives, in consultation with central and human services agencies. A cross-agency board, senior officers group, and a new unit in the FACS cluster were established to drive the implementation of TFM. In the 2016–17 Budget, the government allocated $190 million over four years (2016–17 to 2019–20) to the reform. This resourced the design and commissioning of evidence-based pilots, data analytics work, staffing for the implementation unit and secretariat support for the board and cross-agency collaboration.

As part of the TFM reform, the Department of Premier and Cabinet, NSW Treasury and partnering agencies (NSW Health, Department of Education and Department of Justice) identified various existing programs that targeted vulnerable children and families (such as the preceding whole-of-government ‘Keep Them Safe’ reform coming to an end in June 2020). Funding for these programs, totalling $381 million in 2019–20, was combined to form a nominal ‘investment pool’. The government intended that the TFM Implementation Board would use this pool to direct and prioritise resource allocation to evidence-based interventions for vulnerable children and families in NSW.

This audit assessed whether TFM had effective governance and partnership arrangements in place to enable an evidence-based early intervention investment approach for vulnerable children and families in NSW. We addressed the audit objective with the following audit questions:

• Was the TFM reform driven by effective governance arrangements?
• Was the TFM reform supported by effective cross-agency collaboration?
• Has the TFM reform generated an evidence base to inform a cross-agency investment approach in the future?

The audit did not seek to assess the outcomes for children, young people and families achieved by TFM programs and projects.

Their Futures Matter (TFM) is a whole-of-government reform to deliver improved outcomes for vulnerable children, young people and their families.

Supported by a cross-agency TFM Board, and the TFM Unit in the then Department of Family and Community Services (FACS), the reform aimed to develop whole-of-government evidence-based early intervention investment approaches for vulnerable children and families in NSW.

Governance refers to the structures, systems and practices that an organisation has in place to:

• assign decision-making authorities and establish the organisation's strategic direction
• oversee the delivery of its services, the implementation of its policies, and the monitoring and mitigation of its key risks
• report on its performance in achieving intended results, and drive ongoing improvements.

We examined whether the TFM reform was driven by effective governance arrangements and cross-agency collaboration.

The reform agenda and timeframe set down for Their Futures Matter (TFM) were ambitious. This chapter assesses whether the TFM Board and TFM Unit had the capability, capacity and clout within government to deliver the reform agenda.

Creating a robust evidence base was important for Their Futures Matter, in order to:

• identify effective intervention strategies to improve supports and outcomes for vulnerable children and families
• make efficient use of taxpayer money to assist the maximum number of vulnerable children and families
• inform the investment-based approach for future funding allocation.

This chapter assesses whether the TFM reform has developed an evidence base to inform cross-agency investment decisions.

Appendix one – Response from agency

Appendix two – TFM governance entities

Appendix three – TFM Human Services Data Set

Appendix four – TFM pilot programs

Appendix five – About the audit

Appendix six – Performance auditing

Copyright notice

© Copyright reserved by the Audit Office of New South Wales. All rights reserved. No part of this publication may be reproduced without prior consent of the Audit Office of New South Wales. The Audit Office does not accept responsibility for loss or damage suffered by any person acting on or refraining from action as a result of any of this material.

Parliamentary reference - Report number #337 - released 24 July 2020

This is a follow-up to the Auditor-General's November 2016 report on the CBD South East Sydney Light Rail project. This follow-up report assessed whether Transport for NSW has updated and consolidated information about project costs and benefits.

The audit found that Transport for NSW has not consistently and accurately updated project costs, limiting the transparency of reporting to the public.

The Auditor-General reports that the total cost of the project will exceed $3.1 billion, which is above the revised cost of $2.9 billion published in November 2019. $153.84 million of additional costs are due to omitted costs for early enabling works, the small business assistance package and financing costs attributable to project delays.

The report makes four recommendations to Transport for NSW to publicly report on the final project cost, the updated expected project benefits, the benefits achieved in the first year of operations and the average weekly journey times.

Read full report (PDF)

The CBD and South East Light Rail is a 12 km light rail network for Sydney. It extends from Circular Quay along George Street to Central Station, through Surry Hills to Moore Park, then to Kensington and Kingsford via Anzac Parade and Randwick via Alison Road and High Street.

Transport for NSW (TfNSW) is responsible for planning, procuring and delivering the Central Business District and South East Light Rail (CSELR) project. In December 2014, TfNSW entered into a public private partnership with ALTRAC Light Rail as the operating company (OpCo) responsible for delivering, operating and maintaining the CSELR. OpCo engaged Alstom and Acciona, who together form its Design and Construct Contractor (D&C).

On 14 December 2019, passenger services started on the line between Circular Quay and Randwick. Passenger services on the line between Circular Quay and Kingsford commenced on 3 April 2020.

In November 2016, the Auditor-General published a performance audit report on the CSELR project. The audit found that TfNSW would deliver the CSELR at a higher cost with lower benefits than in the approved business case, and recommended that TfNSW update and consolidate information about project costs and benefits and ensure the information is readily accessible to the public.

In November 2018, the Public Accounts Committee (PAC) examined TfNSW's actions taken in response to our 2016 performance audit report on the CSELR project. The PAC recommended that the Auditor-General consider undertaking a follow-up audit on the CSELR project. The purpose of this follow-up performance audit is to assess whether TfNSW has effectively updated and consolidated information about project costs and benefits for the CSELR project.

Appendix one – Response from agency

Appendix two – Governance and reporting arrangements for the CSELR

Appendix three – 2018 CSELR governance changes

Appendix four – About the audit

Appendix five – Performance auditing

Copyright notice

© Copyright reserved by the Audit Office of New South Wales. All rights reserved. No part of this publication may be reproduced without prior consent of the Audit Office of New South Wales. The Audit Office does not accept responsibility for loss or damage suffered by any person acting on or refraining from action as a result of any of this material.

Parliamentary reference - Report number #335 - released 11 June 2020

This report focuses on how the NSW Police Force managed a $100 million program to acquire new technology. The program invested in technologies intended to make police work safer and quicker. These included body-worn video (BWV) cameras, smart phone devices, mobile fingerprint scanners and hand-held drug testing devices.

The audit found that while the NSW Police Force mostly managed the ‘Policing for Tomorrow’ program effectively, investment decision making could be improved in the future. The NSW Police Force missed an opportunity to take a whole-of-organisation approach to identify capability gaps and target the acquired technologies to plug these.

The NSW Police Force has processes in place to monitor the benefits of some of the larger technology, but it does not do this consistently for all procured technology. It could not demonstrate that smaller projects are improving the efficiency or effectiveness of policing.

The audit also found that the NSW Police Force does not routinely engage with external stakeholders on the use or impacts of new technology that changes how officers interact with the public, noting that this will not always be possible for particularly sensitive procurements that involve covert technologies or methodologies.

The Auditor-General made three recommendations to guide improvement of NSW Police Force ICT procurement, benefits management and stakeholder engagement processes.

Read full report (PDF)

Ahead of the March 2015 election, the NSW Government announced a $100 million Policing for Tomorrow fund for the NSW Police Force to acquire technology intended to make police work safer and quicker. The announcement committed the NSW Police Force to several investment priorities, including body-worn video (BWV) cameras, smart phone devices (MobiPOL), mobile fingerprint scanners and hand-held drug testing devices. Otherwise, the NSW Police Force was allowed flexibility in identifying and resourcing suitable projects.

This audit assessed whether the Policing for Tomorrow fund was effectively managed to improve policing in New South Wales. We addressed the audit objective with the following audit questions:

• Did the NSW Police Force efficiently and effectively identify, acquire, implement and maintain technology resourced by the fund?
• Did the NSW Police Force establish effective governance arrangements for administering the fund, and for monitoring expected benefits and unintended consequences?
• Did technology implemented under the fund improve the efficiency and effectiveness of policing in New South Wales?

We examined how effectively the NSW Police Force governed the Policing for Tomorrow fund, to ensure that key accountability and decision-making arrangements were in place to direct the $100 million spend to appropriate technologies. We also assessed how the NSW Police Force acquired, implemented and maintained technology funded by Policing for Tomorrow to determine the effectiveness of the relevant asset management.

The Policing for Tomorrow election commitment aimed to invest in technology to ‘make police work safer and quicker – meaning more time on the street combatting crime’. We assessed whether the NSW Police Force ensured that funded technologies have improved policing efficiency and effectiveness. We did not seek to independently assure the benefits or outcomes resulting from the technologies.

Appendix one – Response from agency

Appendix two – Policing for Tomorrow projects and expenditure

Appendix three – About the audit

Appendix four – Performance auditing

Copyright notice

© Copyright reserved by the Audit Office of New South Wales. All rights reserved. No part of this publication may be reproduced without prior consent of the Audit Office of New South Wales. The Audit Office does not accept responsibility for loss or damage suffered by any person acting on or refraining from action as a result of any of this material.

Parliamentary reference - Report number #334 - released 2 June 2020

This report focuses on whether Destination NSW (DNSW) can demonstrate that its support for major events achieves value for money.

The audit found that DNSW’s processes for assessing and evaluating the major events it funds are mostly effective, but its public reporting does not provide enough transparency.

DNSW provides clear information to event organisers seeking funding and has a comprehensive methodology for conducting detailed event assessments. However, the reasons for decisions to progress events from the initial assessment to the detailed assessment stage are not documented in sufficient detail.

DNSW does not publish detailed information about the events it funds or the outcomes of these events. This means that members of the public are unable to see whether its activities achieve value for money. However, DNSW’s internal reporting to its key decision‑makers, including the CEO, the Board and the Minister is appropriate.

The Auditor-General made four recommendations to DNSW, aimed at improving the transparency of its activities, improving the documentation of decisions and certain compliance matters, and streamlining its approach to assessing and evaluating events that receive smaller amounts of funding.

Read full report (PDF)

Destination NSW (DNSW) provides funding to attract a range of major events to New South Wales, including high-profile professional sports matches and tournaments, musicals, art and museum exhibitions, and participation-focused events such as festivals and sports events that members of the public can enter. The NSW Government's rationale for providing funding is to encourage event organisers to hold events in New South Wales, and to ensure that events held in New South Wales maximise the potential for attracting overseas and interstate visitors.

This audit assessed whether DNSW can demonstrate that its support for major events achieves value for money. In making this assessment, the audit examined whether:

• DNSW effectively assesses proposals to support major events
• DNSW effectively evaluates the impact of its support for major events.

This audit focused on DNSW's work to attract major events to New South Wales. It did not assess DNSW's tourism promotion or development work, which includes developing tourism strategies, marketing and advertising campaigns, national and international partnerships, and regional programs.

Appendix one – Response from Destination NSW

Appendix two – About the audit 

Appendix three – Performance auditing

Copyright Notice

© Copyright reserved by the Audit Office of New South Wales. All rights reserved. No part of this publication may be reproduced without prior consent of the Audit Office of New South Wales. The Audit Office does not accept responsibility for loss or damage suffered by any person acting on or refraining from action as a result of any of this material.

Parliamentary reference - Report number #332 - released 9 April 2020.

The Auditor-General for New South Wales, Margaret Crawford, released a report today on whether the Department of Communities and Justice (the department) effectively supports the efficient operation of the District Criminal Court system.

The audit found that in the provision of data and technology services, the department is not effectively supporting the efficient operation of the District Criminal Court system. The department has insufficient controls in place to ensure that data in the system is always accurate.

The department is also using outdated technology and could improve its delivery of technical support to courts.

The audit also assessed the implementation of the Early Appropriate Guilty Pleas reform. This reform aims to improve court efficiency by having more cases resolved earlier with a guilty plea in the Local Court. The audit found that the department effectively governed the implementation of the reform but is not measuring achievement of expected benefits, placing the objectives of the reform at risk.

The Auditor-General made seven recommendations to the department, aimed at improving the controls around courts data, reporting on key performance indicators, improving regional technical support and measuring the success of the Early Appropriate Guilty Pleas reform. 

The District Court is the intermediate court in the New South Wales court system. It hears most serious criminal matters, except murder, treason and piracy. The Department of Communities and Justice (the Department) provides support to the District Court in a variety of ways. For example, it provides security services, library services and front-desk services. This audit examined three forms of support that the Department provides to the District Court:

• data collection, reporting and analysis - the Department collects data from cases in its case management system, JusticeLink, based on the orders Judges make in court and court papers
• technology - the Department provides technology to courts across New South Wales, as well as technical support for this technology
• policy - the Department is responsible for proposing and implementing policy reforms.

Recent years have seen a worsening of District Court efficiency, as measured in the Productivity Commission's Report on Government Services (RoGS). Efficiency in the court system is typically measured through timeliness of case completion. There is evidence that timeliness has worsened. For example, the median time from arrest to finalisation of a case in the District Court increased from 420 days in 2012–13 to 541 days in 2017–18.

As a result, the government has announced a range of measures to improve court performance, particularly in the District Court. These measures included the Early Appropriate Guilty Pleas (EAGP) reform. One of the objectives of EAGP is to improve court efficiency, which would be achieved by having more cases resolve with a guilty plea in the Local Court.

This audit assessed whether the Department of Communities and Justice effectively supports the efficient operation of the District Criminal Court system. We assessed this with the following lines of inquiry:

• Does the Department effectively collect, analyse and report performance information relevant to court efficiency?
• Does the Department effectively provide technology to support the efficient working of the courts?
• Does the Department have effective plans, governance and monitoring for the Early Appropriate Guilty Pleas reform?

The audit did not consider other support functions provided by the Department. Further information on the audit, including detailed audit criteria, may be found in Appendix two.

The Department is responsible for providing technology to the courts, which can improve the efficiency of court operations by making them faster and cheaper. The Department is also responsible for providing technical support to courtrooms and registries. It is important that technical support is provided in a timely manner because some technical incidents can delay court sittings and thus impact on court efficiency. A 2013 Organisation for Economic Co‑operation and Development report emphasised the importance of technology and digitisation for reducing trial length.

While the Department may provide technology to the courts, they are not responsible for deciding when, how or if the technology is used in the courtroom.

The Department is using a significant amount of outdated technology, risking court delays

As of April 2019, the whole court system had 2,389 laptops or desktop computers out of warranty, 56.0 per cent of the court system's fleet. The court system also had 786 printing devices out of their normal warranty period, 75.1 per cent of all printers in use. The Department also advised that many of its court audio transcription machines are out of date. These machines must be running for the court to sit and thus it is critical that they are maintained to a high degree. The then Department of Justice estimated the cost of aligning its hardware across the whole Department with desired levels at $14.0 million per year for three years. Figures for the court system were not calculated but they are likely to be a significant portion of this figure.

Using outdated technology poses a risk to the court system as older equipment may be more likely to break down, potentially delaying courts or slowing down court services. In the court system throughout 2018, hardware made up 30.8 per cent of all critical incidents reported to technical support and 41.9 per cent of all high priority incidents. In addition, 16.2 per cent of all reported issues related to printing devices or printing.

From 2017 to 2018, technical support incidents from courts or court services increased. There were 4,379 technical support incidents in 2017, which increased significantly to 9,186 in 2018. The Department advised that some outside factors may have contributed to this increase. The Department was rolling out its new incident recording system throughout 2017, meaning that there would be an under‑reporting of incidents in that year. The Department also advised that throughout 2018 there was a greater focus on ensuring that every issue was logged, which had not previously been the case. Despite these factors, the use of outdated technology has likely increased the risk of technology breakages and may have contributed to the increase in requests for technical support.

Refreshing technology on a regular basis would reduce the risk of hardware failures and ensure that equipment is covered by warranty.

The Department did not meet all court technical support targets in 2017 and 2018

The Digital and Technology Services branch (DTS) was responsible for providing technical support to the courts and the Courts and Tribunal Services branch prior to July 2019. DTS provided technical support in line with a Service Level Agreement (SLA) with the Department. In 2017, DTS did not provide this support in a timely manner. Performance improved in 2018, though DTS fell short of its targets for critical and moderate priority incidents. Exhibit 7 outlines DTS' targets under the SLA.

Critical incidents are particularly important for the Department to deal with in a timely manner because these include incidents which may delay a court sitting until resolved or incidents which impact on large numbers of staff. Some of the critical incidents raised with DTS specifically stated that they were delaying a court sitting, often due to transcription machines not working. High priority incidents include those where there is some impact on the functions of the business, which may in turn affect the efficiency of the court system. High priority incidents also include those directly impacting on members of the Judiciary. 

This audit examined DTS' performance against its SLA in the 2017 and 2018 calendar years across the whole court system, not just the District Court. The total number of incidents, as well as critical and high priority incidents, can be seen in Exhibit 8.

The Department's results against its SLA in 2017 and 2018 are shown in Exhibit 9.

The Early Appropriate Guilty Pleas (EAGP) reform consists of five main elements:

• early disclosure of evidence from NSW Police Force to the prosecution and defence
• early certification of what the accused is going to be charged with to minimise changes
• mandatory criminal case conferencing between the prosecutor and accused's representation
• changes to Local Court case management
• more structured sentence discounts.

More detailed descriptions of each of these changes can be found in the Introduction. These reform elements are anticipated to have three key effects:

• accelerate the timing of guilty pleas
• increase the overall proportion of guilty pleas
• decrease the average length of contested trials.

Improving District Court efficiency is one of the stated aims of EAGP, which would be achieved by having more cases resolve in the Local Court and having fewer defendants plead guilty on the day of their trial in the District Court. The reform commenced in April 2018 and it is too early to state the impact of this reform on District Court efficiency.

The Department is responsible for delivering EAGP in conjunction with other justice sector agencies. They participated in the Steering Committee and the Working Groups, as well as providing the Project Management Office (PMO).

The Department is not measuring the economic benefits stated in the EAGP business case

The business case for EAGP listed nine quantifiable benefits which were expected to be derived from the achievement of the three key effects listed above. The Department is not measuring one of these benefits and is not measuring the economic benefits for five more, as shown in Exhibit 12.

Benefit	Economic benefit (over ten years)	Being measured?
Accelerated timing of guilty pleas	$54.6m
Increased guilty plea rate	$90.7m
Decreased average trial length	$27.5m
A reduction in the delay of indictable matters proceeding to trial	N/A
Increase the number of finalised matters per annum	N/A
Reduction of the current backlog of criminal trials in the District Court	N/A
Reduction in bed pressure on the correction system due to reduced average time in custody	$13.7m
Productivity improvements due to reduction in wasted effort	$53.3m
Bankable cost savings due to jury empanelment avoided	$2.5m

Exhibit 12: The Department's measurement of quantifiable benefits

Key

Measuring

Not measuring economic benefit

Not measuring

While it is too early to comment on the overall impact of EAGP, better practice in benefits realisation involves an ongoing effort to monitor benefits to ensure that the reform is on target and determine whether any corrective action is needed.

The Department is measuring the number of finalised matters per annum and while the Department is not measuring the reduction in the backlog as part of this program, this measure is reported as part of the Department's internal reporting framework. The Department is not monitoring the reduction in delay of indictable matters proceeding to trial directly as part of this reform, but this does form part of the monthly Operational Performance Report which the Department sends to the EAGP Steering Committee.

The Department is not monitoring any of the economic benefits stated in the business case. These economic benefits are a mixture of bankable savings and productivity improvements. This amounts to a total of $242.3 million over ten years which was listed in the business case as potential economic benefits from the implementation of this reform against the total cost of $206.9 million over ten years. The Department is collecting proxy indicators which would assist in these calculations for several indicators, but it is not actively monitoring these savings. For example, the Department is monitoring average trial length, but is not using this information to calculate economic benefits derived from changes in trial length.

The Department is also not collecting information related to the average length of custody as part of this program. This means that it is unable to determine if EAGP is putting less pressure on the correctives system and it is not possible for the Department to calculate the savings from this particular benefit.

While stakeholders are optimistic about the impact of EAGP, not measuring the expected benefits stated in the business case means that the Department does not know if the reform is achieving what it was designed to achieve. Further, the Department does not know if it must take corrective action to ensure that the program achieves the stated benefits. These two things put the overall program benefits at risk.

The Department has not assigned responsibility for the realisation of each benefit stated in the business case. The Department holds the Steering Committee responsible for the realisation of all benefits. Benefits realisation is the process which ensures that the agency reaches benefits as stated in the business case. Assigning responsibility for benefits realisation to the Steering Committee rather than individuals is not in line with good practice.

Good practice benefits realisation involves assigning responsibility for the realisation of each benefit to an individual at the business unit level. This ensures there is a single point of accountability for each part of the program with knowledge of the benefit and the ability to take corrective action if it looks like that benefit will not be realised. This responsibility should sit at the operational level where detailed action can most easily be undertaken. The role of a Steering Committee in benefits realisation is to ensure that responsible parties are monitoring their benefits and taking appropriate corrective action.

The Department advised that it believes the Steering Committee should have responsibility for the realisation of benefits due to the difficulty of attributing the achievement of each benefit to one part of the reform alone. Given the Steering Committee meets only quarterly, it is not well placed to take action in response to variances in performance.

BOCSAR are planning to undertake an overall evaluation of EAGP which is planned for release in 2021. Undertaking this evaluation will require high quality data to gain an understanding of the drivers of the reform. However, data captured throughout the first year of EAGP has proven unreliable, which may reduce the usefulness of BOCSAR's evaluation. These data issues were discussed in Exhibit 5 in Chapter 2, above. Access to accurate data is vital for conducting any program evaluation and inaccurate data raises the risk that the BOCSAR evaluation will not be able to provide an accurate evaluation of the impact of EAGP.

In addition to the BOCSAR evaluation, the Department had plans for a series of 'snapshot' evaluations for some of the key elements of the reform to ensure that they were operating effectively. These were initially delayed due to an efficiency dividend which affected EAGP. In August 2019, the Department commissioned a review of the implementation of several key success factors for EAGP.

The implementation stage of EAGP had clear governance, lines of authority and communication. The Steering Committee, each Working Group and each agency had clear roles and responsibilities, and these were organised through a Project Management Office (PMO) provided by the former Department of Justice. The governance structure throughout the implementation phase can be seen at Exhibit 13.

The Steering Committee was established in December 2016 and met regularly from March 2017. It comprised senior members of key government agencies, as well as the Chief Judge and the Chief Magistrate for most of the duration of the implementation period. The Steering Committee met at least monthly throughout the life of the program. The Steering Committee was responsible for overseeing the delivery of EAGP and making key decisions relating to implementation, including spending decisions. The Chief Judge and the Chief Magistrate abstained from financial decisions. The Steering Committee updated the governance and membership of the Steering Committee as appropriate throughout the life of the reform.

Appendix one – Response from agency
 
Appendix two – About the audit 

Appendix three – Performance auditing 

Copyright Notice

© Copyright reserved by the Audit Office of New South Wales. All rights reserved. No part of this publication may be reproduced without prior consent of the Audit Office of New South Wales. The Audit Office does not accept responsibility for loss or damage suffered by any person acting on or refraining from action as a result of any of this material.

Parliamentary Reference: Report number #329 - released 18 December 2019

This report examined whether HealthShare NSW, a part of NSW Health, has the required contract management capability to effectively manage goods and services contracts valued over $250,000. 

The report found that HealthShare has a procurement framework that should support effective contract management, but it is not applying it consistently. In particular, the audit found that HealthShare was not applying key contract management elements to over 80 per cent of the high-value contracts it manages. The audit also found that HealthShare’s contract management practices were limited by inadequate performance monitoring.

'Effective contract management is essential to ensure the contracts HealthShare enters into are delivering as expected and ensuring value for money,' said the Auditor-General. 'Without this, the value for money or savings HealthShare achieves when it negotiates these contracts is at risk of being eroded over the life of the contract.'

The report recommends that NSW Health develop a performance improvement plan to ensure HealthShare is fully compliant with procurement policies and that NSW Health meets its obligations under the Government's Accreditation Program for Goods and Services Procurement.

HealthShare is a NSW Health entity responsible for providing shared services, including procurement, to support the delivery of patient care within the NSW health system. In 2018, HealthShare procured high value goods and services contracts with an annual estimated total spend of around $1.8 billion, with most of the contracts of long duration.

NSW Government agencies are increasingly delivering services and projects through contracts with third parties. These contracts can be complex and governments face challenges in negotiating and implementing them effectively. A robust contract management framework helps ensure all parties meet their obligations, contractual relationships are well managed, agencies achieve value for money, and deliverables meet the required standards and agreed timeframes.

Contract management capability is a broad term, which can include aspects of individual staff capability (such as staff knowledge, skills and experience) as well as organisational capability (such as policies, frameworks and processes).

The NSW Procurement Board is responsible for overseeing the Government's procurement system, setting policy and ensuring compliance. It has accredited the Health Administration Corporation (HAC) to procure goods and services with no upper financial limit. Under the terms of this accreditation, the Secretary, NSW Health (as head of HAC) has delegated the procurement of high-value (over $250,000) goods and services contracts within NSW Health to only the Ministry of Health and HealthShare NSW (HealthShare).

HealthShare NSW (HealthShare) is a NSW Health entity responsible for providing shared services, including procurement, to support the delivery of patient care within the NSW health system. In 2018, HealthShare procured high-value goods and services contracts with an annual estimated total spend of around $1.8 billion, with most of the contracts of long duration.

HealthShare’s Contract Management Guide states that, without rigorous contract management, 75 per cent of projected sourcing savings can disappear within 18 months of the contract starting.

This audit examined whether HealthShare has the required capability to effectively manage high-value goods and services contracts. Contracts we examined included critical items such as food services in hospitals, patient transport services, intravenous equipment and kidney dialysis services, where risks include patient safety as well as value for money. We did not examine infrastructure, construction or information communication and technology contracts. We also did not examine HealthShare’s sourcing processes, including identifying business needs, tendering and contract award.

We assessed HealthShare against the following criteria:

1. HealthShare's systems, policies and procedures support effective contract management and are consistent with relevant frameworks, policies and guidelines.
2. HealthShare has capable personnel to effectively conduct the monitoring activities throughout the life of the contract.

We included the NSW Public Service Commission and NSW Treasury, through NSW Procurement, as auditees because they administer policies which directly affect contract management capability. These include:

• NSW Procurement Board Directions and policies
• NSW Government Procurement Policy Framework
• Accreditation Program for Goods and Services Procurement
• the NSW Public Sector Capability Framework.

NSW Procurement was transferred to NSW Treasury from the former Department of Finance, Services and Innovation on 1 July 2019 as part of changes to government administrative arrangements.

Appendix one – Response from agencies

Appendix two – Contract performance management summary

Appendix three – About the audit

Appendix four – Performance auditing

© Copyright reserved by the Audit Office of New South Wales. All rights reserved. No part of this publication may be reproduced without prior consent of the Audit Office of New South Wales. The Audit Office does not accept responsibility for loss or damage suffered by any person acting on or refraining from action as a result of any of this material.

Parliamentary Reference: Report number #328 - released 31 October 2019

A report released by the Auditor-General for New South Wales, Margaret Crawford, has found that NSW Health is not forming effective partnerships with Aboriginal communities to plan, design and deliver appropriate mental health services. There is limited evidence that NSW Health is using the knowledge and expertise of Aboriginal communities to guide how mental health care is structured and delivered.

Mental illness (including substance use disorders) is the main contributor to lower life expectancy and increased mortality in the Aboriginal population of New South Wales. It contributes to a higher burden of disease and premature death at rates that are 40 per cent higher than the next highest chronic disease group, cardiovascular disease.¹ 

Aboriginal people have significantly higher rates of mental illness than non Aboriginal people in New South Wales. They are more likely to present at emergency departments in crisis or acute phases of mental illness than the rest of the population and are more likely to be admitted to hospital for mental health treatments.² 

In acknowledgement of the significant health disparities between Aboriginal and non Aboriginal people, NSW Health implemented the NSW Aboriginal Health Plan 2013 2023 (the Aboriginal Health Plan). The overarching message of the Aboriginal Health Plan is ‘to build respectful, trusting and effective partnerships with Aboriginal communities’ and to implement ‘integrated planning and service delivery’ with sector partners. Through the Plan, NSW Health commits to providing culturally appropriate and ‘holistic approaches to the health of Aboriginal people'.

The mental health sector is complex, involving Commonwealth, state and non government service providers. In broad terms, NSW Health has responsibility to support patients requiring higher levels of clinical support for mental illnesses, while the Commonwealth and non government organisations offer non acute care such as assessments, referrals and early intervention treatments.

The NSW Health network includes 15 Local Health Districts and the Justice Health and Forensic Mental Health Network that provide care to patients during acute and severe phases of mental illness in hospitals, prisons and community service environments. This includes care to Aboriginal patients in the community at rates that are more than four times higher than the non Aboriginal population. Community services are usually provided as follow up after acute admissions or interactions with hospital services. The environments where NSW Health delivers mental health care include:

• hospital emergency departments, for short term assessment and referral
• inpatient hospital care for patients in acute and sub acute phases of mental illness
• mental health outpatient services in the community, such as support with medications
• custodial mental health services in adult prisons and juvenile justice centres.

The NSW Government is reforming its mental health funding model to incrementally shift the balance from hospital care to enhanced community care. In 2018–19, the NSW Government committed $400 million over four years into early intervention and specialist community mental health teams.

This audit assessed the effectiveness of NSW Health’s planning and coordination of mental health services and service pathways for Aboriginal people in New South Wales. We addressed the audit objective by answering three questions: 

1. Is NSW Health using evidence to plan and inform the availability of mental health services for Aboriginal people in New South Wales?
2. Is NSW Health collaborating with partners to create accessible mental health service pathways for Aboriginal people?
3. Is NSW Health collaborating with partners to ensure the appropriateness and quality of mental health services for Aboriginal people?

In this report, the term ‘Aboriginal people’ is used to describe both Aboriginal and Torres Strait Islander peoples. The Audit Office of NSW acknowledges the diversity of traditional countries and Aboriginal language groups across the state of New South Wales.

In May 2019, the Audit Office of New South Wales invited Aboriginal mental health clinicians and policy experts from government and non-government organisations to attend a one-day workshop. Workshop attendees advised on factors that improve the quality and appropriateness of mental health care for Aboriginal people in New South Wales. They described appropriate mental health care as:

• culturally safe, allowing Aboriginal people to draw strength in their identity, culture and community
• person centred and focussed on individual needs
• delivered by culturally competent staff with no bias
• holistic, trauma-informed and focussed on early intervention where possible
• delivered in places that are appropriate including outreach to homes and communities
• welcoming of the involvement of local Aboriginal community and connected to local knowledge and expertise including totems and kinship structures. 

The definition of 'appropriate' mental health care for Aboriginal people throughout this report is based on this advice.

Aboriginal people access emergency services at much higher rates than non-Aboriginal people

The choices that people make in relation to health service options provide some insight into the suitability and appropriateness of the service to their needs.

Aboriginal people have different mental health service use patterns than non-Aboriginal people. Aboriginal people are much more likely to be in a crisis situation before receiving mental health services, usually in an emergency department of a hospital.

Aboriginal people make up three per cent of the total New South Wales population, but they constitute 11 per cent of emergency department presentations for mental health treatments. In regional areas, Aboriginal people make up 20.5 per cent of presentations at emergency departments for mental health reasons. 

A number of factors help to explain Aboriginal mental health service usage patterns. According to government and non-government mental health organisations:

• emergency department services are better known to Aboriginal people than other mental health services
• community-based models of care are not appropriate for Aboriginal people
• Aboriginal people are reluctant to access community-based mental health services to prevent crisis situations
• community mental health services are not available for Aboriginal people after hours and during the weekend, so emergency services are the only option.

The statewide proportions of Aboriginal people presenting at emergency departments for mental health treatments has been increasing over time (Exhibit 6).

Appendix one – Response from agency

Appendix two – The NSW Aboriginal Health Plan

Appendix three – About the audit

Appendix four – Performance auditing

Parliamentary Reference: Report number #326 - released 29 August 2019

Copyright reserved by the Audit Office of New South Wales. All rights reserved. No part of this publication may be reproduced without prior consent of the Audit Office of New South Wales. The Audit Office does not accept responsibility for loss or damage suffered by any person acting on or refraining from action as a result of any of this material.

The report found the clearing of native vegetation on rural land is not effectively regulated and managed. The processes supporting the regulatory framework are weak and there is no evidence-based assurance that clearing of native vegetation is carried out in accordance with approvals. 

In 2014 an expert panel completed a review of biodiversity legislation in NSW. The panel’s recommendations included repealing the Native Vegetation Act 2003, proposing a new Act with the goal of maintaining a healthy, productive and resilient environment for the greatest wellbeing of the community, and recommending that management of native vegetation in the context of existing agricultural management would be assisted and supervised by Local Land Services (LLS).

Following the panel report, the NSW Government undertook major biodiversity conservation and land management reforms which saw the introduction of the Biodiversity Conservation Act 2016 (NSW) and the Local Land Services Amendment Act 2016 (NSW). The reforms commenced in August 2017. The Native Vegetation Act 2003, the Threatened Species Conservation Act 1995, the Nature Conservation Trust Act 2001, and parts of the National Parks and Wildlife Act 1974 were repealed.

Under the legislative reforms, the Biodiversity Conservation Act 2016 and Local Land Services Amendment Act 2016, which amended the Local Land Services Act 2013, aim to ensure a balanced approach to land management and biodiversity conservation in NSW.

A core objective of the Biodiversity Conservation Act 2016 is to conserve biodiversity at bioregional and state scales. A core objective of the Local Land Service Act 2013 is to ensure the proper management of natural resources in the social, economic and environmental interests of the state, consistently with the principles of ecologically sustainable development.

The integrated package of reforms included:

• new arrangements that allow land owners to improve productivity while responding to environmental risks
• new ways to assess and manage the biodiversity impacts of development
• a new state Environmental Planning Policy for managing impacts on native vegetation in urban areas
• significant investment in conservation of private land
• a risk-based system for regulating human and business interactions with native plants and animals
• streamlined approvals and dedicated resources to help reduce the regulatory burden.

Transition to this land management framework began on 25 August 2017 with the commencement of the Land Management (Native Vegetation) Code.

The overall objectives of the reforms are:

• to arrest and ultimately reverse the current decline in the state’s biodiversity while facilitating ecologically sustainable development, in particular efficient and sustainable agricultural development
• enable landholders to improve the efficiency of their agricultural systems and take a more active role in providing incentive and supporting landholders to improve the condition and function of their ecological systems. 

The objective of this audit is to assess whether the clearing of native vegetation in rural areas is effectively regulated and managed by the Office of Environment and Heritage (OEH) and LLS under these legislative frameworks. The audit also examined the progress of the Biodiversity Conservation Trust in implementing the Biodiversity Conservation Investment Strategy as a counterbalance to rural land clearing. 

At the time of this audit OEH was responsible for preparing the Native Vegetation Regulatory map and for compliance enforcement in relation to unlawful land clearing. Post 1 July 2019, under machinery of government changes, OEH will be abolished and its activities relevant to this audit will be moved to the new Department of Planning, Industry and Environment. For the purposes of this audit we will continue to refer to it as OEH. 

Local Land Services (LLS) is responsible for processing notifications and issuing certificates to landholders for managing the thinning or clearing of native vegetation on rural land through the ‘Land Management (Native Vegetation) Code 2018’ (the Code). This work includes monitoring and reporting on the implementation of the Code, including the establishment and management of set asides.

OEH is responsible for compliance and enforcement in relation to unlawful land clearing. It is also responsible for producing the NVR map, designed to show landholders where land clearing can occur without approval, where approval is required, and where land clearing is not permitted. Post 1 July 2019, under machinery of government changes, OEH will be abolished and its activities relevant to this audit will be moved to the new Department of Planning, Industry and Environment.

Appendix one - Response from agencies

Appendix two - Authorisations for thinning and clearing, and restoration initiatives under the Native Vegetation Act 2003

Appendix three - About the audit

Appendix four - Performance auditing

Parliamentary Reference: Report number #324 - released 27 June 2019

Copyright reserved by the Audit Office of New South Wales. All rights reserved. No part of this publication may be reproduced without prior consent of the Audit Office of New South Wales. The Audit Office does not accept responsibility for loss or damage suffered by any person acting on or refraining from action as a result of any of this material.

The Department of Justice has relied heavily on temporary responses to accommodate growing prisoner numbers according to a report released today by the Acting Auditor-General for New South Wales, Ian Goodwin.

At the time of this audit, the NSW Department of Justice (DOJ) was responsible for delivering custodial corrections services in New South Wales through its Corrective Services NSW division (Corrective Services NSW). From 1 July 2019, the Department of Family and Community Services and Justice will be responsible for these functions. 

Within DOJ, Corrective Services NSW is responsible for administering sentences and legal orders through custodial and community-based management of adult offenders. Its key priorities are:

• providing safe, secure and humane management of prisoners
• reducing reoffending
• improving community safety and confidence in the justice system. 

The prison population in New South Wales grew by around 40 per cent between 2012 to 2018, from 9,602 to 13,630 inmates. This rate of growth was higher than experienced prior to 2012. DOJ forecasts growth to continue over the short and longer-term. 

DOJ has responded to inmate population growth by doubling-up and tripling-up the number of prison beds in cells, reactivating previously closed prisons, and a $3.8 billion program of new prison capacity. DOJ has also developed a long-term prison infrastructure strategy that projects long-term needs and recommended investments to meet these needs. 

This audit assessed how efficiently and effectively DOJ is responding to growth in the NSW prison population. In this report, we have not analysed the sources of demand or recommended ways that custody may be avoided. These are largely government policy issues. 

The Productivity Commission’s Report on Government Services outlines the performance indicator framework for corrective services in Australia (Appendix three). We have used measures from this framework to assess the efficiency and effectiveness of DOJ’s responses to prison bed capacity needs. 

In this section, we analyse system-wide indicators as DOJ has not consistently published or reported data for individual correctional centres over the period of review.
 

Appendix one - Response from agency

Appendix two - Managing women in custody

Appendix three - Corrective services performance indicator framework

Appendix four - About the audit

Appendix five – Performance auditing

Parliamentary Reference: Report number #319 - released 24 May 2019