The Auditor-General for New South Wales, Margaret Crawford, released a report today examining the management of the One TAFE NSW modernisation program.

In 2016, the Government released 'A Vision for TAFE NSW' which stated that TAFE NSW needed to become more flexible, efficient and competitive. It set out the need to progressively reduce significant cost inefficiencies, including by moving away from separate institutes to a single institute model. TAFE NSW established the One TAFE NSW modernisation program to deliver on that vision.

The Auditor General found that the One TAFE NSW modernisation program did not deliver against its key objectives within planned timeframes. The modernisation program originally aimed to realise $250 million in annual savings from 2018–19. Because of project delays and higher than expected transition costs, TAFE NSW did not meet the original savings target. TAFE NSW has made progress on key elements of the program and anticipates that savings will be realised in coming years.

The report makes two recommendations to improve governance arrangements for delivering on commercial objectives and increasing transparency of non commercial activities. 

The report also identifies a series of lessons for future government transformation programs.

TAFE NSW is the public provider of Vocational Education and Training (VET) in New South Wales. In 2018, TAFE NSW enrolled 436,000 students in more than 1,200 courses at around 130 locations across the State.

There have been major policy changes impacting TAFE NSW over the past decade. Under the Smart and Skilled reform, TAFE NSW started to compete with other Registered Training Organisations (RTOs) for a share of the student market.

In 2016, the NSW Government released 'A Vision for TAFE NSW'. The Vision stated that a failure to adapt to market circumstances had left TAFE NSW with unsustainable costs and inefficiencies. To address this, TAFE NSW needed to become more flexible, efficient and competitive. It set out that TAFE NSW must progressively reduce significant cost inefficiencies, including by moving away from a model of separate institutes to a One  TAFE NSW model. The NSW Government set TAFE NSW a target to achieve savings through implementing the Vision.

TAFE NSW established the One TAFE NSW modernisation program to deliver on that vision. The program initially aimed to deliver savings of $250 million per year from 2018–19, but this target was reviewed and updated as the program was being delivered.

This audit assessed whether TAFE NSW effectively managed the One TAFE NSW modernisation program to deliver on the NSW Government's vision for TAFE NSW. In making this assessment, the audit examined whether:

• delivery of the program was well planned
• the program was driven by sound governance arrangements
• TAFE NSW is making progress against the intended outcomes of the program.

The audit focused on the effectiveness of planning, governance and reporting arrangements. It examined five projects within the overall modernisation program as case studies.

Appendix one – Response from agency

Appendix two – About the audit

Appendix three – Performance auditing

© Copyright reserved by the Audit Office of New South Wales. All rights reserved. No part of this publication may be reproduced without prior consent of the Audit Office of New South Wales. The Audit Office does not accept responsibility for loss or damage suffered by any person acting on or refraining from action as a result of any of this material.

Parliamentary reference - Report number #346 - released 17 December 2020

This report provides parliament and other users of the Transport cluster’s financial statements with the results of our audits, our observations, analysis, conclusions and recommendations in the following areas:

• financial reporting
• audit observations
• the impact of emergencies and the pandemic.

Financial reporting is an important element of good governance. Confidence and transparency in public sector decision making are enhanced when financial reporting is accurate and timely.

This chapter outlines our audit observations related to the financial reporting of agencies in the Transport cluster for 2020, including any financial implications from the recent emergency events.

Appropriate financial controls help ensure the efficient and effective use of resources and administration of agency policies. They are essential for quality and timely decision making.

This chapter outlines our:

• observations and insights from our financial statement audits of agencies in the Transport cluster
• assessment of how well cluster agencies adapted their systems, policies and procedures, and governance arrangements in response to recent emergencies.

Appendix one – List of 2020 recommendations

Appendix two – Status of 2019, 2018 and 2017 recommendations

Appendix three – Management letter findings

Appendix four – Financial data

Copyright notice

© Copyright reserved by the Audit Office of New South Wales. All rights reserved. No part of this publication may be reproduced without prior consent of the Audit Office of New South Wales. The Audit Office does not accept responsibility for loss or damage suffered by any person acting on or refraining from action as a result of any of this material.

This report analyses the results of our audits of financial statements of the agencies comprising the Stronger Communities cluster for the year ended 30 June 2020. The table below summarises our key observations.

This report provides parliament and other users of the financial statements of agencies in the Stronger Communities cluster with the results of our audits, our observations, analysis, conclusions and recommendations.

Agencies in the Stronger Communities cluster were significantly impacted by the bushfires, floods and the COVID-19 pandemic in 2019–20. Our 2019–20 financial audits of the seven cluster agencies most significantly impacted by the recent emergency events considered:

• the financial implications of the emergency events
• changes to agencies' operating models and control environments
• delivery of new or expanded projects, programs or services at short notice.

Our findings on these seven agencies' responses to the recent emergencies are included throughout this report. These agencies are:

• Department of Communities and Justice
• Fire and Rescue NSW
• NSW Police Force
• Office of the NSW Rural Fire Service
• Office of the NSW State Emergency Service
• Sydney Cricket and Sports Ground Trust
• Venues NSW.

The Department of Communities and Justice is the principal agency of the cluster. The names of all agencies in the Stronger Communities cluster are included in Appendix one.

Financial reporting is an important element of good governance. Confidence and transparency in public sector decision making are enhanced when financial reporting is accurate and timely.

This chapter outlines our audit observations related to the financial reporting of agencies in the Stronger Communities cluster for 2020, including any financial implications from the recent emergency events.

Appropriate financial controls help ensure the efficient and effective use of resources and administration of agency policies. They are essential for quality and timely decision making.

This chapter outlines our:

• observations and insights from our financial statement audits of agencies in the Stronger Communities cluster
• assessment of how well cluster agencies adapted their systems, policies and procedures, and governance arrangements in response to recent emergencies
• review of how the cluster agencies managed the increased risks associated with new programs aimed at stemming the spread of COVID-19 and stimulating the economy.

Appendix one – Timeliness of financial reporting by agency

Appendix two – Management letter findings by agency

Appendix three – List of 2020 recommendations 

Appendix four – Status of 2019 recommendations 

Appendix five – Selected agencies for review of response to emergency events 

Appendix six – Financial data 

Copyright notice

© Copyright reserved by the Audit Office of New South Wales. All rights reserved. No part of this publication may be reproduced without prior consent of the Audit Office of New South Wales. The Audit Office does not accept responsibility for loss or damage suffered by any person acting on or refraining from action as a result of any of this material.

This report analyses the results of our audits of financial statements of the Planning, Industry and Environment cluster agencies for the year ended 30 June 2020. The table below summarises our key observations.

1. Financial reporting

2. Audit observations

This report provides parliament and other users of the Planning, Industry and Environment cluster agencies’ financial statements with the results of our audits, our observations, analysis, conclusions and recommendations in the following areas:

• financial reporting
• audit observations
• the impact of emergencies and the pandemic.

Financial reporting is an important element of good governance. Confidence and transparency in public sector decision making are enhanced when financial reporting is accurate and timely.

The COVID‑19 Legislation Amendment (Emergency Measures–Treasurer) Act 2020 amended legislation administered by the Treasurer to implement further emergency measures as a result of the COVID‑19 pandemic. These amendments:

• allowed the Treasurer to authorise payments from the Consolidated fund until the enactment of the 2020–21 budget – impacting the going concern assessments of cluster agencies
• revised budgetary, financial and annual reporting time frames – impacting the timeliness of financial reporting
• exempted certain statutory bodies and departments from preparing financial statements.

This chapter outlines our audit observations related to the financial reporting of agencies in the Planning, Industry and Environment cluster for 2020, including any financial implications from the recent emergency events.

Appropriate financial controls help ensure the efficient and effective use of resources and administration of agency policies. They are essential for quality and timely decision making.

This chapter outlines our:

• observations and insights from our financial statements audits of agencies in the Planning, Industry and Environment cluster
• assessment of how well cluster agencies adapted their systems, policies and procedures, and governance arrangements in response to recent emergencies
• review of how the cluster agencies managed the increased risks associated with new programs aimed at stemming the spread of COVID-19 and stimulating the economy.

Cluster agencies experienced a range of control and governance related issues in recent years. An increased number of high risk issues and greater proportion of repeat issues were identified as part of our audits. It is important for cluster agencies to promptly address these issues.

Appendix one – List of 2020 recommendations

Appendix two – Status of 2019 recommendations

Appendix three – Financial data

Appendix four – Management letter findings

Appendix five – Timeliness of financial reporting

Appendix six – Selected agencies for review of response to emergency events

The Auditor-General for New South Wales, Margaret Crawford, released a report today titled Education 2020. This report focuses on key observations and findings from the most recent audits of agencies in the Education cluster.

Unqualified audit opinions were issued for all cluster agencies’ financial statements. However, internal control deficiencies were identified across the cluster agencies, including deficiencies in the management of purchasing cards and 15 internal control issues that were repeated from the previous year.

The 2019–20 natural disasters caused widespread damage in both Northern and Southern NSW. The COVID‑19 pandemic further challenged agencies, requiring social distancing and other infection control measures which disrupted the traditional means of teaching students. Agencies have adjusted their operations to respond to these emergency events.

The TAFE Commission’s revenues 2019–20 were impacted by the pandemic. Lower enrolments and an increase in fee-free short courses offered during the year contributed to the result.

Read the PDF report

This report analyses the results of our audits of financial statements of entities within the Education cluster for the year ended 30 June 2020. The table below summarises our key observations and recommendations.

1. Financial reporting 

2. Audit observations

This report provides parliament and other users of the Education cluster’s financial statements with the results of our audits, our observations, analysis, conclusions and recommendations in the following areas:

• financial reporting
• audit observations
• the impact of emergencies and the COVID-19 pandemic.

Financial reporting is an important element of good governance. Confidence and transparency in public sector decision making are enhanced when financial reporting is accurate and timely.

The COVID-19 Legislation Amendment (Emergency Measures–Treasurer) Act 2020 amended legislation administered by the Treasurer to implement further emergency measures as a result of the COVID-19 pandemic. These amendments:

• allowed the Treasurer to authorise payments from the consolidated fund until the enactment of the 2020–21 budget – supporting the going concern assessments of cluster agencies
• revised budgetary, financial and annual reporting time frames – impacting the timeliness of financial reporting
• exempted certain statutory bodies and departments from preparing financial statements.

This chapter outlines our audit observations related to the financial reporting of agencies in the Education cluster for 2020, including any financial implications from the recent emergency events.

Appropriate financial controls help ensure the efficient and effective use of resources and administration of agency policies. They are essential for quality and timely decision making.

This chapter outlines our:

• observations and insights from our financial statement audits of agencies in the Education cluster. It also comments on our review of elements of the financial control framework applied by schools in NSW whose financial results form part of the Department of Education's (the Department) financial statements.
• assessment of how well cluster agencies adapted their systems, policies and procedures, and governance arrangements in response to recent emergencies.

Appendix one – List of 2020 recommendations

Appendix two – Status of 2019 and 2018 recommendations

Appendix three – Financial data

Copyright notice

© Copyright reserved by the Audit Office of New South Wales. All rights reserved. No part of this publication may be reproduced without prior consent of the Audit Office of New South Wales. The Audit Office does not accept responsibility for loss or damage suffered by any person acting on or refraining from action as a result of any of this material.

This report examines whether NSW Health effectively planned and delivered major capital works to meet the demand for health services in New South Wales.

The report found that NSW Health has substantially expanded health infrastructure across New South Wales since 2015. However, the program was driven by Local Health District priorities without assessment of the State’s broader and future‑focussed health requirements.

The report found that unclear decision making roles and responsibilities between Health Infrastructure and the Ministry of Health limited the ability of NSW Health to effectively test and analyse investment options.

Project delays and budget overruns on some major projects indicate that Health Infrastructure's project governance, risk assessment and management systems could be improved.

The Auditor‑General recommends that NSW Health ensure its capital projects offer the greatest value to New South Wales by establishing effective policy guidance and enhancing project governance and management systems.

Read full report (PDF)

Since 2011–12, NSW Health has aimed to improve its facilities and build 'future focused' infrastructure. The NSW Government’s 2015–16 election commitments established a four-year $5.0 billion capital program for NSW Health to build and upgrade more than 60 hospitals and health services. The 2019–20 State Budget committed a further $10.1 billion over four years for another 29 projects. This is the largest investment to date on health capital works in New South Wales.

Recent reviews of infrastructure have recognised that population and demographic growth will require a change in the delivery and composition of health infrastructure, including considering greater use of non-traditional, non-capital health service options and assets.

To ensure that expenditure on capital works represents the best value for money, NSW Health's business cases need to be robust and supported by evidence that demonstrates they are worthy investments. The NSW Process of Facility Planning has been the main framework guiding the detailed planning and development of NSW Health's capital works proposals. This framework was developed by the then NSW Department of Health in 2010. Its aim is to ensure investment proposals are supported by rigorous planning processes that address health service needs and provide value for money.

Infrastructure projects of the complexity and scale being delivered by NSW Health carry inherent risks. For example, unplanned cost escalations can potentially impact on the State’s finances. Unforeseen delays can also reduce the intended benefits. The growth in the State’s health capital spend and project profile, means its exposure to such risks has increased over time.

The objective of this audit was to assess the effectiveness of planning and delivery of major capital works to meet demand for health services in New South Wales. To address this objective, the audit examined whether:

• the Ministry of Health has effective procedures for planning and prioritising investments in major health capital works
• Health Infrastructure develops robust business cases for initiated major capital works that reliably inform government decision making
• Health Infrastructure has effective project governance and management systems that support delivering projects on-time, within budget and achievement of intended benefits.

The audit focused on the Ministry of Health and Health Infrastructure – being the lead agencies within NSW Health responsible for prioritising, planning and delivering major health capital works across the State. The audit examined 13 business cases for eight discrete projects over a ten-year period.

Over the period of review, NSW Government policies for business case development and submission have emphasised that effective governance arrangements are critical to a proposal's successful implementation.

NSW Health's Process of Facility Planning similarly highlights the importance of effective governance and project management for achieving good outcomes. It prescribes a general governance structure managed by Health Infrastructure that can be tailored to the planning and delivery of health infrastructure projects greater than $10.0 million.

The three major hospital redevelopments examined in metropolitan, regional and rural areas had a combined Estimated Total Cost of more than $1.2 billion and comprised eight discrete projects and 13 separate business cases.

Almost all these projects experienced delivery challenges which impacted achievement of their original objectives and intended benefits. This is expected in complex and large-scale health infrastructure programs. However, in some projects the impacts were significant and resulted in substantial delays, unforeseen costs, and diversion of resources from other priority areas.

Our review of the selected case studies highlighted opportunities for enhancing governance and project management. Specifically, it indicates a need for improving transparency in the management of contingencies, risk management and assessments particularly relating to adverse site conditions and the selection of contractors. There is also a need to strengthen forward planning for options to address unfunded priorities within business cases that risk complicating the delivery of future project stages resulting in unforeseen costs and potentially avoidable budget overruns.

In February 2017, the Ministry's Capital Strategy Group approved the use of surplus funds of $13.76 million from Stage 1 of the Hornsby Ku-ring-gai Hospital Redevelopment for new works deemed needed to support Stage 2. Following this decision, Health Infrastructure finalised and submitted a business case addendum for Stage 1 to the Ministry in March 2017, addressing the new works comprising a two-storey building for medical imaging and paediatric floors. The business case addendum also addressed options to fit out and procure major medical imaging equipment. The Ministry approved the Stage 1 business case in July 2017, noting the Ministry's Capital Strategy Group had already approved the use of remaining Stage 1 funds to deliver the new works.

Stage 1 was completed in 2015, almost two years before the Stage 1 business case addendum was prepared in February 2017.

The Ministry's decision to approve the new works using $13.76 million of surplus Stage 1 funds did not comply with the NSW Treasury Circular TC 12/20. This policy establishes the Treasurer's approval must be sought and received before a new capital project with an Estimated Total Cost of $5.0 million or more can be approved by NSW Health. The Ministry therefore exceeded its delegated authority in making this decision, as it was not evident it had sought and received the Treasurer's approval prior to doing so.

Consequently, the surplus Stage 1 funds should not have been used by the Ministry to deliver new works in the circumstances. Instead, they should have been released from the Stage 1 project in accordance with established NSW Health procedures, and the Stage 1 Estimated Total Cost revised down accordingly. This did not occur, and NSW Health ultimately directed $11.0 million in surplus Stage 1 funds to the new works.

These circumstances indicate a need to strengthen transparency and accountability within NSW Health for the approval of new projects, and how contingency funds are used in the management of major health capital works. They also demonstrate the impact of weaknesses with options appraisal as the initial Stage 1 business case did not consider alternative options for addressing the initially unfunded works later covered by the Stage 1 business case addendum and ultimately funded from the Stage 1 contingency provision.

In addition to proposing the above-noted new works, the 2017 Stage 1 Business Case Addendum for the Hornsby-Ku-ring-gai development sought to retrospectively address the estimated funding gap of around $14.0 million for the internal fit out, supply of major medical imaging equipment, and cost to operate the medical imaging service at Hornsby Ku-ring-gai Hospital also not addressed in the originally Stage 1 business case.

The Stage 1 business case addendum considered various procurement options to purchase and run the medical imaging services ranging from State operation purchase options to private operation purchase options.

It recommended outsourcing the operation and provision of equipment to the private sector based on estimated savings to the public sector initially of around $650,000 per annum reducing over time to $270,000. The Ministry endorsed this option in June 2017, but it did not ultimately proceed.

A July 2018 report to the Executive Steering Committee on the project shows NSW Health later decided to deliver operation of the medical imaging unit 'traditionally' with an updated estimate of the cost at approximately $16.4 million. The report also shows the Ministry supported the costs now being met by the Northern Sydney Local Health District.

This means the funding gap previously identified in the Stage 1 business case addendum for fitting out the medical imaging building and supply of major medical equipment would need to be met fully by the State, representing a $16.4 million cost overrun for the project.

Examined reports to the Executive Steering Committee show this was largely funded by the Northern Sydney Local Health District via the disposal of land realising approximately $15.0 million in proceeds.

This initially unforeseen cost, along with the additional $11.0 million for the new works approved under the Stage 1 business case addendum, were ultimately merged with the Stage 2 project initially approved in 2017–18 with an Estimated Total Cost of $200 million.

The 2019–20 State Budget provided an additional $65.0 million for a further Stage 2A to deliver additional built capacity to support outpatient services, enhanced allied health services, re-housed community health services and the delivery of prioritised clinical services unfunded as part of Stage 2. The funds were approved based on an Investment Decision Template (IDT) that examined two options in addition to the base case representing scoping alternatives to the preferred master planned capital solution.

However, we found the IDT showed around 23 per cent of the $65.0 million sought (i.e. $15.0 million) was to be allocated to fund the deficit in Stage 2, which had arisen as a result of project delays due to adverse site conditions. This was not discussed in the IDT.

The February 2020 report to the Executive Steering Committee shows a combined Stage 2 and 2A final forecast cost of $292.6 million against a potential budget of $290.7 million representing an overall deficit for the project of around 0.6 per cent.

However, this favourable final budget position does not transparently show the funding challenges experienced over the project's implementation to-date. The three major budget issues include:

• inappropriate use of around $11.0 million in Stage 1 contingency for originally unfunded works contrary to Treasury policy
• the additional $16.4 million cost unforeseen in the Stage 1 business case for delivering medical imaging services mostly funded through the sale of land
• an additional $15.0 million from Stage 2A to cover the budget overrun in Stage 2 due to adverse site conditions.

The cumulative impact of these events is that Stages 1 and 2 of the Hornsby project cost approximately $42.4 million than it should have in the circumstances around 14 per cent more than what the revised combined Estimated Total Cost for both stages should have been after releasing the $11.0 million in surplus Stage 1 funds, with Stage 2 delayed by around 14 months.

Major construction projects often experience adverse site conditions which can be difficult to fully detect in advance. However, we found this was a common occurrence in the projects we examined sometimes with significant time and/or budget impacts indicating scope to enhance related risk and cost assessments. Specifically:

• Hornsby Ku-ring-gai Hospital Redevelopment Stage 2: adverse site conditions during demolition works resulted in an 11-month delay for delivering the medical imaging unit and 14-month delay completing Stage 2 main works including need for additional $15.0 million in funds to cover the resultant budget deficit for the project.
• Blacktown Mt Druitt Hospital Redevelopment Stage 2: adverse site conditions combined with project complexity delayed completion of the early works by approximately five months. This contributed to the delay in completing the main construction works which occurred around nine months later than planned in the business case.
• Dubbo Health Service Redevelopment Stages 3 and 4: Health Infrastructure advised adverse site conditions including asbestos containing materials and ground conditions delayed works for the main building with completion forecast for March 2021, around 21 months later than planned in the final business case. This resulted in the need for additional $13.5 million to cover increased construction costs and risks, increasing the Stage 3 and 4 forecast final cost from $150 million to $163.5 million as at February 2020.

These examples indicate a risk the cumulative impact of adverse site conditions may be substantial when measured across both time and Health Infrastructure's full delivery program. They also point to potential for Health Infrastructure to achieve efficiencies and improved outcomes from strengthening its approach to assessing and mitigating the risks from adverse site conditions.

Main construction works on Stage 1 of the Dubbo Health Service Redevelopment were completed in October 2015, approximately 13 months later than planned in the final business case. Delays were mainly due to insolvency of the early works contractor resulting in their departure from the project. The ensuing 11-month delay in completing the early works significantly impacted the overall schedule and delivery of main construction works.

The insolvency event was significant as it affected nine separate Health Infrastructure projects – three of which had yet to reach practical completion. It also affected state-funded projects in other sectors. It resulted in the need for additional funding of $11.5 million that was provided in the 2014–15 State Budget increasing the total Stage 1 and 2 budget from $79.8 million to $91.3 million.

Health Infrastructure’s analysis of lessons learned shows it worked actively to mitigate the impacts of the insolvency event across all affected projects. However, it also indicates a risk the lessons were mainly focused on mitigating the impacts after an insolvency event occurred rather than on prevention.

Although Health Infrastructure initially commissioned a financial assessment of the now insolvent early works contractor before engagement, it did not detect any risks of the impending insolvency and instead concluded the contractor was in a strong financial position. However, the contractor became insolvent shortly after commencement approximately seven months later. This indicates a risk of weaknesses in the assessment performed that was not explicitly addressed by the lessons learned.

Delivery of the main construction works were further impacted by disputes with the main works contractor over the scope of works for the renal unit resulting in Health Infrastructure terminating the contract in November 2016 following lengthy negotiations over several months.

The scope of works relating to the renal unit were ultimately transferred to Stages 3 and 4 and were delivered in December 2019, around five years later than originally planned in the business case.

Health Infrastructure advised the delay was ultimately beneficial to the project because the refurbishment works for the renal unit, initially scheduled for Stages 1 and 2, would have been demolished to accommodate the new Western Cancer Centre proposed after Stages 1 and 2 and currently being delivered in parallel with Stages 3 and 4.

Health Infrastructure advised the actual cost of Stages 1 and 2 was $84.7 million against the budget of $91.3 million. The residual $6.6 million relates to the renal works not delivered during Stage 1 and 2 and transferred to Stage 3 and 4.

Health Infrastructure advised the contractual provisions for mitigating insolvency events 'in-flight' are limited highlighting the importance of proactive and effective due diligence prior to engaging contractors for significant construction projects.

Health Infrastructure's 2017-20 Corporate Plan identifies the development of a quality framework to support delivery of future-focused outcomes as a key organisational priority. Related initiatives within the Corporate Plan describe a framework underpinned by a Quality Committee providing advice on:

• records management, to meet the requirements of the State Records Act 1998
• project assurance, to ensure future focused outcomes and enhance Health Infrastructure's Standards, Policies, Procedures and Guidelines, Templates and Design Guidance Notes
• knowledge management and library services, to promote and leverage from project learnings.

Although Health Infrastructure has some elements of a quality framework it is not yet fully in place. Health Infrastructure advised it had yet to establish the quality framework and related committee described in its Corporate Plan due in part to its focus on responding to the growth of its capital program.

Health Infrastructure's Development and Innovation team has been active in supporting continuous improvement in knowledge and project management including development of business cases. Although useful, these initiatives have relied heavily on leveraging and disseminating insights from Gateway reviews and have not formed part of a systematic quality and continuous improvement framework.

The limited focus on the quality of business cases is reflected in internal performance monitoring and reporting which focuses mainly on tracking the delivery of projects against internal benchmarks, often revised from the baselines in the business case, and expenditure against cashflow targets. There is no evident internal monitoring and/or reporting to the Chief Executive and Board on defined quality metrics linked to business case development and staff capability.

Performance reporting on balanced scorecard metrics has similarly focused mainly on process rather than quality and has been inconsistent in recent years.

Appendix one – Response from agency

Appendix two – About the audit

Appendix three – Performance auditing

Appendix four – Ministry of Health planning tools and guidelines

Appendix five – Streamlined investment decision process for Health Capital Projects

Appendix six – Timeline of business cases and relevant policy guidelines

Copyright notice

© Copyright reserved by the Audit Office of New South Wales. All rights reserved. No part of this publication may be reproduced without prior consent of the Audit Office of New South Wales. The Audit Office does not accept responsibility for loss or damage suffered by any person acting on or refraining from action as a result of any of this material.

Parliamentary reference - Report number #338 - released 12 August 2020

The Auditor-General for New South Wales, Margaret Crawford, released a report today examining whether the Department of Communities and Justice had effective governance and partnership arrangements in place to deliver ‘Their Futures Matter’.

Their Futures Matter was intended to place vulnerable children and families at the heart of services, and direct investment to where funding and programs deliver the greatest social and economic benefits. It was a four-year whole-of-government reform in response to the 2015 Tune Review of out-of-home care.

The Auditor-General found that while important foundations were put in place, and new programs trialled, the key objective to establish an evidence-based whole-of-government early intervention approach for vulnerable children and families in NSW was not achieved.

Governance and cross-agency partnership arrangements to deliver Their Futures Matter were found to be ineffective. 'Their Futures Matter lacked mechanisms to secure cross portfolio buy‑in and did not have authority to drive reprioritisation of government investment', the Auditor-General said.

At the reform’s close, the majority of around $380 million in investment funding remains tied to existing agency programs, with limited evidence of their comparative effectiveness or alignment with Their Futures Matter policy objectives. The reform concluded on 30 June 2020 without a strategy or plan in place to achieve its intent.

The Auditor-General made four recommendations to the Department of Communities and Justice, aimed at improving implementation of outstanding objectives, revising governance arrangements, and utilising the new human services data set to address the intent of the reform. However, these recommendations respond only in part to the findings of the audit.

According to the Auditor-General, ‘Cross-portfolio leadership and action is required to ensure a whole-of-government response to delivering the objectives of Their Futures Matter to improve outcomes for vulnerable children, young people and their families in New South Wales.’

Read full report (PDF)

In 2016, the NSW Government launched 'Their Futures Matter' (TFM) - a whole-of-government reform aimed at delivering improved outcomes for vulnerable children, young people and their families. TFM was the government's key response to the 2015 Independent Review of Out of Home Care in New South Wales (known as 'the Tune Review').

The Tune Review found that, despite previous child protection reforms, the out of home care system was ineffective and unsustainable. It highlighted that the system was not client-centred and was failing to improve the long-term outcomes for vulnerable children and families. The review found that the greatest proportion of relevant expenditure was made in out of home care service delivery rather than in evidence-based early intervention strategies to support children and families when vulnerabilities first become evident to government services (such as missed school days or presentations to health services).

The then Department of Family and Community Services (FACS) designed the TFM reform initiatives, in consultation with central and human services agencies. A cross-agency board, senior officers group, and a new unit in the FACS cluster were established to drive the implementation of TFM. In the 2016–17 Budget, the government allocated $190 million over four years (2016–17 to 2019–20) to the reform. This resourced the design and commissioning of evidence-based pilots, data analytics work, staffing for the implementation unit and secretariat support for the board and cross-agency collaboration.

As part of the TFM reform, the Department of Premier and Cabinet, NSW Treasury and partnering agencies (NSW Health, Department of Education and Department of Justice) identified various existing programs that targeted vulnerable children and families (such as the preceding whole-of-government ‘Keep Them Safe’ reform coming to an end in June 2020). Funding for these programs, totalling $381 million in 2019–20, was combined to form a nominal ‘investment pool’. The government intended that the TFM Implementation Board would use this pool to direct and prioritise resource allocation to evidence-based interventions for vulnerable children and families in NSW.

This audit assessed whether TFM had effective governance and partnership arrangements in place to enable an evidence-based early intervention investment approach for vulnerable children and families in NSW. We addressed the audit objective with the following audit questions:

• Was the TFM reform driven by effective governance arrangements?
• Was the TFM reform supported by effective cross-agency collaboration?
• Has the TFM reform generated an evidence base to inform a cross-agency investment approach in the future?

The audit did not seek to assess the outcomes for children, young people and families achieved by TFM programs and projects.

Their Futures Matter (TFM) is a whole-of-government reform to deliver improved outcomes for vulnerable children, young people and their families.

Supported by a cross-agency TFM Board, and the TFM Unit in the then Department of Family and Community Services (FACS), the reform aimed to develop whole-of-government evidence-based early intervention investment approaches for vulnerable children and families in NSW.

Governance refers to the structures, systems and practices that an organisation has in place to:

• assign decision-making authorities and establish the organisation's strategic direction
• oversee the delivery of its services, the implementation of its policies, and the monitoring and mitigation of its key risks
• report on its performance in achieving intended results, and drive ongoing improvements.

We examined whether the TFM reform was driven by effective governance arrangements and cross-agency collaboration.

The reform agenda and timeframe set down for Their Futures Matter (TFM) were ambitious. This chapter assesses whether the TFM Board and TFM Unit had the capability, capacity and clout within government to deliver the reform agenda.

Creating a robust evidence base was important for Their Futures Matter, in order to:

• identify effective intervention strategies to improve supports and outcomes for vulnerable children and families
• make efficient use of taxpayer money to assist the maximum number of vulnerable children and families
• inform the investment-based approach for future funding allocation.

This chapter assesses whether the TFM reform has developed an evidence base to inform cross-agency investment decisions.

Appendix one – Response from agency

Appendix two – TFM governance entities

Appendix three – TFM Human Services Data Set

Appendix four – TFM pilot programs

Appendix five – About the audit

Appendix six – Performance auditing

Copyright notice

© Copyright reserved by the Audit Office of New South Wales. All rights reserved. No part of this publication may be reproduced without prior consent of the Audit Office of New South Wales. The Audit Office does not accept responsibility for loss or damage suffered by any person acting on or refraining from action as a result of any of this material.

Parliamentary reference - Report number #337 - released 24 July 2020

This is a follow-up to the Auditor-General's November 2016 report on the CBD South East Sydney Light Rail project. This follow-up report assessed whether Transport for NSW has updated and consolidated information about project costs and benefits.

The audit found that Transport for NSW has not consistently and accurately updated project costs, limiting the transparency of reporting to the public.

The Auditor-General reports that the total cost of the project will exceed $3.1 billion, which is above the revised cost of $2.9 billion published in November 2019. $153.84 million of additional costs are due to omitted costs for early enabling works, the small business assistance package and financing costs attributable to project delays.

The report makes four recommendations to Transport for NSW to publicly report on the final project cost, the updated expected project benefits, the benefits achieved in the first year of operations and the average weekly journey times.

Read full report (PDF)

The CBD and South East Light Rail is a 12 km light rail network for Sydney. It extends from Circular Quay along George Street to Central Station, through Surry Hills to Moore Park, then to Kensington and Kingsford via Anzac Parade and Randwick via Alison Road and High Street.

Transport for NSW (TfNSW) is responsible for planning, procuring and delivering the Central Business District and South East Light Rail (CSELR) project. In December 2014, TfNSW entered into a public private partnership with ALTRAC Light Rail as the operating company (OpCo) responsible for delivering, operating and maintaining the CSELR. OpCo engaged Alstom and Acciona, who together form its Design and Construct Contractor (D&C).

On 14 December 2019, passenger services started on the line between Circular Quay and Randwick. Passenger services on the line between Circular Quay and Kingsford commenced on 3 April 2020.

In November 2016, the Auditor-General published a performance audit report on the CSELR project. The audit found that TfNSW would deliver the CSELR at a higher cost with lower benefits than in the approved business case, and recommended that TfNSW update and consolidate information about project costs and benefits and ensure the information is readily accessible to the public.

In November 2018, the Public Accounts Committee (PAC) examined TfNSW's actions taken in response to our 2016 performance audit report on the CSELR project. The PAC recommended that the Auditor-General consider undertaking a follow-up audit on the CSELR project. The purpose of this follow-up performance audit is to assess whether TfNSW has effectively updated and consolidated information about project costs and benefits for the CSELR project.

Appendix one – Response from agency

Appendix two – Governance and reporting arrangements for the CSELR

Appendix three – 2018 CSELR governance changes

Appendix four – About the audit

Appendix five – Performance auditing

Copyright notice

© Copyright reserved by the Audit Office of New South Wales. All rights reserved. No part of this publication may be reproduced without prior consent of the Audit Office of New South Wales. The Audit Office does not accept responsibility for loss or damage suffered by any person acting on or refraining from action as a result of any of this material.

Parliamentary reference - Report number #335 - released 11 June 2020

This report focuses on how the NSW Police Force managed a $100 million program to acquire new technology. The program invested in technologies intended to make police work safer and quicker. These included body-worn video (BWV) cameras, smart phone devices, mobile fingerprint scanners and hand-held drug testing devices.

The audit found that while the NSW Police Force mostly managed the ‘Policing for Tomorrow’ program effectively, investment decision making could be improved in the future. The NSW Police Force missed an opportunity to take a whole-of-organisation approach to identify capability gaps and target the acquired technologies to plug these.

The NSW Police Force has processes in place to monitor the benefits of some of the larger technology, but it does not do this consistently for all procured technology. It could not demonstrate that smaller projects are improving the efficiency or effectiveness of policing.

The audit also found that the NSW Police Force does not routinely engage with external stakeholders on the use or impacts of new technology that changes how officers interact with the public, noting that this will not always be possible for particularly sensitive procurements that involve covert technologies or methodologies.

The Auditor-General made three recommendations to guide improvement of NSW Police Force ICT procurement, benefits management and stakeholder engagement processes.

Read full report (PDF)

Ahead of the March 2015 election, the NSW Government announced a $100 million Policing for Tomorrow fund for the NSW Police Force to acquire technology intended to make police work safer and quicker. The announcement committed the NSW Police Force to several investment priorities, including body-worn video (BWV) cameras, smart phone devices (MobiPOL), mobile fingerprint scanners and hand-held drug testing devices. Otherwise, the NSW Police Force was allowed flexibility in identifying and resourcing suitable projects.

This audit assessed whether the Policing for Tomorrow fund was effectively managed to improve policing in New South Wales. We addressed the audit objective with the following audit questions:

• Did the NSW Police Force efficiently and effectively identify, acquire, implement and maintain technology resourced by the fund?
• Did the NSW Police Force establish effective governance arrangements for administering the fund, and for monitoring expected benefits and unintended consequences?
• Did technology implemented under the fund improve the efficiency and effectiveness of policing in New South Wales?

We examined how effectively the NSW Police Force governed the Policing for Tomorrow fund, to ensure that key accountability and decision-making arrangements were in place to direct the $100 million spend to appropriate technologies. We also assessed how the NSW Police Force acquired, implemented and maintained technology funded by Policing for Tomorrow to determine the effectiveness of the relevant asset management.

The Policing for Tomorrow election commitment aimed to invest in technology to ‘make police work safer and quicker – meaning more time on the street combatting crime’. We assessed whether the NSW Police Force ensured that funded technologies have improved policing efficiency and effectiveness. We did not seek to independently assure the benefits or outcomes resulting from the technologies.

Appendix one – Response from agency

Appendix two – Policing for Tomorrow projects and expenditure

Appendix three – About the audit

Appendix four – Performance auditing

Copyright notice

© Copyright reserved by the Audit Office of New South Wales. All rights reserved. No part of this publication may be reproduced without prior consent of the Audit Office of New South Wales. The Audit Office does not accept responsibility for loss or damage suffered by any person acting on or refraining from action as a result of any of this material.

Parliamentary reference - Report number #334 - released 2 June 2020

The Auditor-General for New South Wales, Margaret Crawford, released a report today on whether the Department of Communities and Justice (the department) effectively supports the efficient operation of the District Criminal Court system.

The audit found that in the provision of data and technology services, the department is not effectively supporting the efficient operation of the District Criminal Court system. The department has insufficient controls in place to ensure that data in the system is always accurate.

The department is also using outdated technology and could improve its delivery of technical support to courts.

The audit also assessed the implementation of the Early Appropriate Guilty Pleas reform. This reform aims to improve court efficiency by having more cases resolved earlier with a guilty plea in the Local Court. The audit found that the department effectively governed the implementation of the reform but is not measuring achievement of expected benefits, placing the objectives of the reform at risk.

The Auditor-General made seven recommendations to the department, aimed at improving the controls around courts data, reporting on key performance indicators, improving regional technical support and measuring the success of the Early Appropriate Guilty Pleas reform. 

The District Court is the intermediate court in the New South Wales court system. It hears most serious criminal matters, except murder, treason and piracy. The Department of Communities and Justice (the Department) provides support to the District Court in a variety of ways. For example, it provides security services, library services and front-desk services. This audit examined three forms of support that the Department provides to the District Court:

• data collection, reporting and analysis - the Department collects data from cases in its case management system, JusticeLink, based on the orders Judges make in court and court papers
• technology - the Department provides technology to courts across New South Wales, as well as technical support for this technology
• policy - the Department is responsible for proposing and implementing policy reforms.

Recent years have seen a worsening of District Court efficiency, as measured in the Productivity Commission's Report on Government Services (RoGS). Efficiency in the court system is typically measured through timeliness of case completion. There is evidence that timeliness has worsened. For example, the median time from arrest to finalisation of a case in the District Court increased from 420 days in 2012–13 to 541 days in 2017–18.

As a result, the government has announced a range of measures to improve court performance, particularly in the District Court. These measures included the Early Appropriate Guilty Pleas (EAGP) reform. One of the objectives of EAGP is to improve court efficiency, which would be achieved by having more cases resolve with a guilty plea in the Local Court.

This audit assessed whether the Department of Communities and Justice effectively supports the efficient operation of the District Criminal Court system. We assessed this with the following lines of inquiry:

• Does the Department effectively collect, analyse and report performance information relevant to court efficiency?
• Does the Department effectively provide technology to support the efficient working of the courts?
• Does the Department have effective plans, governance and monitoring for the Early Appropriate Guilty Pleas reform?

The audit did not consider other support functions provided by the Department. Further information on the audit, including detailed audit criteria, may be found in Appendix two.

The Department is responsible for providing technology to the courts, which can improve the efficiency of court operations by making them faster and cheaper. The Department is also responsible for providing technical support to courtrooms and registries. It is important that technical support is provided in a timely manner because some technical incidents can delay court sittings and thus impact on court efficiency. A 2013 Organisation for Economic Co‑operation and Development report emphasised the importance of technology and digitisation for reducing trial length.

While the Department may provide technology to the courts, they are not responsible for deciding when, how or if the technology is used in the courtroom.

The Department is using a significant amount of outdated technology, risking court delays

As of April 2019, the whole court system had 2,389 laptops or desktop computers out of warranty, 56.0 per cent of the court system's fleet. The court system also had 786 printing devices out of their normal warranty period, 75.1 per cent of all printers in use. The Department also advised that many of its court audio transcription machines are out of date. These machines must be running for the court to sit and thus it is critical that they are maintained to a high degree. The then Department of Justice estimated the cost of aligning its hardware across the whole Department with desired levels at $14.0 million per year for three years. Figures for the court system were not calculated but they are likely to be a significant portion of this figure.

Using outdated technology poses a risk to the court system as older equipment may be more likely to break down, potentially delaying courts or slowing down court services. In the court system throughout 2018, hardware made up 30.8 per cent of all critical incidents reported to technical support and 41.9 per cent of all high priority incidents. In addition, 16.2 per cent of all reported issues related to printing devices or printing.

From 2017 to 2018, technical support incidents from courts or court services increased. There were 4,379 technical support incidents in 2017, which increased significantly to 9,186 in 2018. The Department advised that some outside factors may have contributed to this increase. The Department was rolling out its new incident recording system throughout 2017, meaning that there would be an under‑reporting of incidents in that year. The Department also advised that throughout 2018 there was a greater focus on ensuring that every issue was logged, which had not previously been the case. Despite these factors, the use of outdated technology has likely increased the risk of technology breakages and may have contributed to the increase in requests for technical support.

Refreshing technology on a regular basis would reduce the risk of hardware failures and ensure that equipment is covered by warranty.

The Department did not meet all court technical support targets in 2017 and 2018

The Digital and Technology Services branch (DTS) was responsible for providing technical support to the courts and the Courts and Tribunal Services branch prior to July 2019. DTS provided technical support in line with a Service Level Agreement (SLA) with the Department. In 2017, DTS did not provide this support in a timely manner. Performance improved in 2018, though DTS fell short of its targets for critical and moderate priority incidents. Exhibit 7 outlines DTS' targets under the SLA.

Critical incidents are particularly important for the Department to deal with in a timely manner because these include incidents which may delay a court sitting until resolved or incidents which impact on large numbers of staff. Some of the critical incidents raised with DTS specifically stated that they were delaying a court sitting, often due to transcription machines not working. High priority incidents include those where there is some impact on the functions of the business, which may in turn affect the efficiency of the court system. High priority incidents also include those directly impacting on members of the Judiciary. 

This audit examined DTS' performance against its SLA in the 2017 and 2018 calendar years across the whole court system, not just the District Court. The total number of incidents, as well as critical and high priority incidents, can be seen in Exhibit 8.

The Department's results against its SLA in 2017 and 2018 are shown in Exhibit 9.

The Early Appropriate Guilty Pleas (EAGP) reform consists of five main elements:

• early disclosure of evidence from NSW Police Force to the prosecution and defence
• early certification of what the accused is going to be charged with to minimise changes
• mandatory criminal case conferencing between the prosecutor and accused's representation
• changes to Local Court case management
• more structured sentence discounts.

More detailed descriptions of each of these changes can be found in the Introduction. These reform elements are anticipated to have three key effects:

• accelerate the timing of guilty pleas
• increase the overall proportion of guilty pleas
• decrease the average length of contested trials.

Improving District Court efficiency is one of the stated aims of EAGP, which would be achieved by having more cases resolve in the Local Court and having fewer defendants plead guilty on the day of their trial in the District Court. The reform commenced in April 2018 and it is too early to state the impact of this reform on District Court efficiency.

The Department is responsible for delivering EAGP in conjunction with other justice sector agencies. They participated in the Steering Committee and the Working Groups, as well as providing the Project Management Office (PMO).

The Department is not measuring the economic benefits stated in the EAGP business case

The business case for EAGP listed nine quantifiable benefits which were expected to be derived from the achievement of the three key effects listed above. The Department is not measuring one of these benefits and is not measuring the economic benefits for five more, as shown in Exhibit 12.

Benefit	Economic benefit (over ten years)	Being measured?
Accelerated timing of guilty pleas	$54.6m
Increased guilty plea rate	$90.7m
Decreased average trial length	$27.5m
A reduction in the delay of indictable matters proceeding to trial	N/A
Increase the number of finalised matters per annum	N/A
Reduction of the current backlog of criminal trials in the District Court	N/A
Reduction in bed pressure on the correction system due to reduced average time in custody	$13.7m
Productivity improvements due to reduction in wasted effort	$53.3m
Bankable cost savings due to jury empanelment avoided	$2.5m

Exhibit 12: The Department's measurement of quantifiable benefits

Key

Measuring

Not measuring economic benefit

Not measuring

While it is too early to comment on the overall impact of EAGP, better practice in benefits realisation involves an ongoing effort to monitor benefits to ensure that the reform is on target and determine whether any corrective action is needed.

The Department is measuring the number of finalised matters per annum and while the Department is not measuring the reduction in the backlog as part of this program, this measure is reported as part of the Department's internal reporting framework. The Department is not monitoring the reduction in delay of indictable matters proceeding to trial directly as part of this reform, but this does form part of the monthly Operational Performance Report which the Department sends to the EAGP Steering Committee.

The Department is not monitoring any of the economic benefits stated in the business case. These economic benefits are a mixture of bankable savings and productivity improvements. This amounts to a total of $242.3 million over ten years which was listed in the business case as potential economic benefits from the implementation of this reform against the total cost of $206.9 million over ten years. The Department is collecting proxy indicators which would assist in these calculations for several indicators, but it is not actively monitoring these savings. For example, the Department is monitoring average trial length, but is not using this information to calculate economic benefits derived from changes in trial length.

The Department is also not collecting information related to the average length of custody as part of this program. This means that it is unable to determine if EAGP is putting less pressure on the correctives system and it is not possible for the Department to calculate the savings from this particular benefit.

While stakeholders are optimistic about the impact of EAGP, not measuring the expected benefits stated in the business case means that the Department does not know if the reform is achieving what it was designed to achieve. Further, the Department does not know if it must take corrective action to ensure that the program achieves the stated benefits. These two things put the overall program benefits at risk.

The Department has not assigned responsibility for the realisation of each benefit stated in the business case. The Department holds the Steering Committee responsible for the realisation of all benefits. Benefits realisation is the process which ensures that the agency reaches benefits as stated in the business case. Assigning responsibility for benefits realisation to the Steering Committee rather than individuals is not in line with good practice.

Good practice benefits realisation involves assigning responsibility for the realisation of each benefit to an individual at the business unit level. This ensures there is a single point of accountability for each part of the program with knowledge of the benefit and the ability to take corrective action if it looks like that benefit will not be realised. This responsibility should sit at the operational level where detailed action can most easily be undertaken. The role of a Steering Committee in benefits realisation is to ensure that responsible parties are monitoring their benefits and taking appropriate corrective action.

The Department advised that it believes the Steering Committee should have responsibility for the realisation of benefits due to the difficulty of attributing the achievement of each benefit to one part of the reform alone. Given the Steering Committee meets only quarterly, it is not well placed to take action in response to variances in performance.

BOCSAR are planning to undertake an overall evaluation of EAGP which is planned for release in 2021. Undertaking this evaluation will require high quality data to gain an understanding of the drivers of the reform. However, data captured throughout the first year of EAGP has proven unreliable, which may reduce the usefulness of BOCSAR's evaluation. These data issues were discussed in Exhibit 5 in Chapter 2, above. Access to accurate data is vital for conducting any program evaluation and inaccurate data raises the risk that the BOCSAR evaluation will not be able to provide an accurate evaluation of the impact of EAGP.

In addition to the BOCSAR evaluation, the Department had plans for a series of 'snapshot' evaluations for some of the key elements of the reform to ensure that they were operating effectively. These were initially delayed due to an efficiency dividend which affected EAGP. In August 2019, the Department commissioned a review of the implementation of several key success factors for EAGP.

The implementation stage of EAGP had clear governance, lines of authority and communication. The Steering Committee, each Working Group and each agency had clear roles and responsibilities, and these were organised through a Project Management Office (PMO) provided by the former Department of Justice. The governance structure throughout the implementation phase can be seen at Exhibit 13.

The Steering Committee was established in December 2016 and met regularly from March 2017. It comprised senior members of key government agencies, as well as the Chief Judge and the Chief Magistrate for most of the duration of the implementation period. The Steering Committee met at least monthly throughout the life of the program. The Steering Committee was responsible for overseeing the delivery of EAGP and making key decisions relating to implementation, including spending decisions. The Chief Judge and the Chief Magistrate abstained from financial decisions. The Steering Committee updated the governance and membership of the Steering Committee as appropriate throughout the life of the reform.

Appendix one – Response from agency
 
Appendix two – About the audit 

Appendix three – Performance auditing 

Copyright Notice

© Copyright reserved by the Audit Office of New South Wales. All rights reserved. No part of this publication may be reproduced without prior consent of the Audit Office of New South Wales. The Audit Office does not accept responsibility for loss or damage suffered by any person acting on or refraining from action as a result of any of this material.

Parliamentary Reference: Report number #329 - released 18 December 2019